You are not logged in.

Main Contractor for the AMS Classroom Upgrade in Block A at Pirinoa School

This tender is using the new split file responses feature on GETS. The agency has indicated that they would like to receive responses separated by price and non price components. Please keep this in mind when preparing your response for submission via GETS.


Tender Closed
RFx ID : 27589297
Tender Name : Main Contractor for the AMS Classroom Upgrade in Block A at Pirinoa School
Reference # :
Open Date : Monday, 26 June 2023 9:00 AM (Pacific/Auckland UTC+12:00)
Close Date  : Thursday, 20 July 2023 5:00 PM (Pacific/Auckland UTC+12:00)
Department/Business Unit : Board of Trustees - Approve by BoT - ie. School Principal
Tender Type : Request for Tenders (RFT)
Tender Coverage : Sole Agency  [?]
Categories :
  • 72000000 - Building and Facility Construction and Maintenance Services
  • Wellington
Exemption Reason : None
Required Pre-qualifications : None
Contact : Ian Rattray
04 526 7711
Alternate Physical Delivery Address  :
Alternate Physical Fax Number  :
Agency Address : NEW ZEALAND

The BoT at Pirinoa School is seeking an experienced and reputable main contractor to undertake the Alterations in A Block to upgrade the teaching spaces. The work involves Internal alterations and refurbishment of wall floor and ceiling finishes, as outlined in the tender document prepared by IR Group Ltd.
• It is envisaged that work will be undertaken as a single stage project undertaken during school term time operating under a CPU and H&S plan. The final programme will be negotiated with the successful contractor, but the work will be ready to be undertaken in the second half of 2023.
• Project consultants are:
o Project Manager: Ian Rattray
o Lead Designer: Krish Rudra @ IR Group

Required solution (method and approach)
The Contract Works required are:
• Targeted demolition and internal strip out.
• Carpentry work
• Plumbing & drainage
• Electrical, fire and security
• Finishing trades, painting and make good internals.
• The works affect Block A on site

The Contractor will be engaged through a Medium Works Contract (Construction contracts for works).
• Timeframes are:
• preferred Start date: Mid to late August 2023
• preferred Due Date for Completion: December 2023
• Work will be undertaken during school term time.

RFx Outcome

This tender has been awarded.

  • Wai Build - York Street, Masterton, 5810, NEW ZEALAND
    Value $ 100,500

Further Award Information:
The three respondents were evaluated for their non priced attributes and then the price score was added in. Waibuild won the contract based on the highest weighted attribute score.

Award Date: Monday, 11 March 2024 (Pacific/Auckland UTC+13:00)
Date RFx was completed/updated: Wednesday, 3 April 2024 12:28 PM (Pacific/Auckland UTC+13:00)