GETS Open Tenders or Quotes

Dargaville Primary School Drainage Remedial Works

Ministry of Education - School Infrastructure — Thu, 27 Aug 2026 23:00:00 GMT

RFx ID:	34802403
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 28 August 2026 11:00 AM +12:00
Close date:	Friday, 29 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Northland
Overview:	This project will address the remaining drainage issues across School site to reduce surface water flooding. To minimise surface water flooding across the Dargaville Primary School site, by completing the remaining stormwater drainage remediation and redirecting water away from buildings and high-use areas: • Block 1 (Rooms 8 & 9) — Redirect stormwater around Block 1. • Site — Redirect all stormwater above SWMH005 (large catchment) and install pumping stations in Sump004 and SWMH004 • Block 14 — Cut back concrete against the cladding at the end of block and install new drainage to divert water away from the building. • Block 3 — Connect downpipes to stormwater.

Fire Alarm Upgrade - Wellsford School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35346225
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland Northland
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Wellsford School, Wellsford. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Wellsford School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Waipu School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35345951
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland Northland
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Waipu School, Waipu. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Waipu School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Tauraroa Area School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35345824
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland Northland
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Tauraroa Area School, Northland. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Tauraroa Area School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Oxford Area School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35345666
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Canterbury
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Oxford Area School, Oxford. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Oxford Area School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Kaurihohore School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35343015
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland Northland
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Kaurihohore School, Kauri. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Kaurihohore School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Howick Intermediate School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35342865
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Howick Intermediate School, Auckland. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Howick Intermediate School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Green Bay High School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35342020
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Green Bay High School, Auckland. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Green Bay High School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Gladstone School (Auckland)

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35341728
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Gladstone School, Mount Albert. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Gladstone School (Auckland) is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Epsom Normal School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35341583
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Epsom Normal School, Auckland. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Epsom Normal School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Drury School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35341438
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland Waikato
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Drury School, Auckland. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Drury School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Conifer Grove School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35341274
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Conifer Grove School, Auckland. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Conifer Grove School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Timaru Girls High School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35314317
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Canterbury
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Timaru Girls High School, Timaru. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Timaru Girls High School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Taumarunui High School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35314087
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Manawatu-Wanganui Waikato
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Taumarunui High School, Taumarunui. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Taumarunui School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Tamatea High School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35313954
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Hawke's Bay
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Tamatea High School, Napier. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Tamatea High School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Rutherford School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35313822
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Rutherford School, Auckland. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Rutherford School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Pukekohe North School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35313772
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland Waikato
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Pukekohe North School, Auckland. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Pukekohe North School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Ormond School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35313580
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Bay of Plenty Gisborne Hawke's Bay
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Ormond School, Ormond. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Ormond School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Kaitaia School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35313244
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland Northland
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Kaitaia School, Kaitaia. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Kaitaia School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Hillsborough School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35313102
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Hillsborough School, Auckland. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Hillsborough School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Henderson North School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35312948
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Henderson North School, Auckland. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Henderson North School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Dawson School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35312781
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland Waikato
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Dawson School, Auckland. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Dawson School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Cockle Bay School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35312737
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland Waikato
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Cockle Bay School, Auckland. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Cockle Bay School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Clevedon School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35312486
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland Waikato
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Clevedon School, Auckland. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Clevedon School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Carisbrook School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35312346
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Otago Southland
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Carisbrook School, Dunedin. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Carisbrook School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Buckland School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35312206
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland Waikato
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Buckland School, Buckland. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Buckland School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Bombay School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35312007
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland Waikato
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Bombay School, Bombay. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Bombay School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Ashley Rakahuri School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35311816
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Canterbury
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Ashley Rakahuri School, Ashley. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Ashley Rakahuri School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Fire Alarm Upgrade - Amuri Area School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35311422
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Friday, 15 January 2027 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Canterbury
Overview:	The Ministry of Education (The Buyer) is seeking proposals for the upgrade of the fire protection for Amuri Area School, Culverden. Over the last 18 years the Ministry of Education have upgraded over 700 fire alarm systems at schools throughout New Zealand. The aim of the program is to replace all old type B class change and obsolete systems with ones complying with the current building code requirements and New Zealand Standards. We are now into stage 27 of the program and Amuri Area School is in the next group of schools to qualify under the program. The specification has been changed from previous stages of the program. Ensure you carefully read it for the changes. A pre-tender meeting to discuss expectations and changes will be held at 10am on Wednesday 11 November 2026. Please register for this here: https://forms.cloud.microsoft/r/42SJ1hpnsF

Matamata Intermediate - New Canopy Structure - Design & Build Contractors

Ministry of Education - School Infrastructure — Tue, 03 Nov 2026 20:00:00 GMT

RFx ID:	35394249
Organisation:	Ministry of Education - School Infrastructure
Open date:	Wednesday, 4 November 2026 9:00 AM +13:00
Close date:	Monday, 21 December 2026 4:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland Bay of Plenty Waikato
Overview:	Matamata Intermediate Board of Trustees are seeking registrations of interest from design & build contractors to design & construct a new canopy structure over an existing sport turf. Registrations of Interest (refer attached 'ROI' Document) + questions relating to this project are to be submitted via the GETS website. The Board of Trustees reserves the final right to accept or decline any registration of interest received for this project.

Main Contractor for the Blocks A, B, C, D, E: Heating Replacement at Orewa Primary School

Ministry of Education - School Infrastructure — Wed, 04 Nov 2026 20:00:00 GMT

RFx ID:	35393304
Organisation:	Ministry of Education - School Infrastructure
Open date:	Thursday, 5 November 2026 9:00 AM +13:00
Close date:	Saturday, 12 December 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for Orewa Primary School (the School) – Blocks A, B, C, D, E: Heating Replacement – Main Building Contractor (the Contract Works).

Main Contractor for the Blocks B, C, D, E, M: Plumbing Items & Vinyl Replacement at Orewa Primary School

Ministry of Education - School Infrastructure — Wed, 04 Nov 2026 20:00:00 GMT

RFx ID:	35393074
Organisation:	Ministry of Education - School Infrastructure
Open date:	Thursday, 5 November 2026 9:00 AM +13:00
Close date:	Saturday, 12 December 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for Orewa Primary School (the School) – Blocks B, C, D, E, M: Plumbing Items & Vinyl Replacement – Main Building Contractor (the Contract Works).

Main Contractor for the Block 8: Window Replacement at Glenavon School

Ministry of Education - School Infrastructure — Wed, 04 Nov 2026 20:00:00 GMT

RFx ID:	35392119
Organisation:	Ministry of Education - School Infrastructure
Open date:	Thursday, 5 November 2026 9:00 AM +13:00
Close date:	Saturday, 12 December 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for Glenavon School (the School) – Block 8: Window Replacement – Main Building Contractor (the Contract Works).

Main Contractor for the Blocks 1, 3, 4, 8: Roof Works at Glenavon School

Ministry of Education - School Infrastructure — Wed, 04 Nov 2026 20:00:00 GMT

RFx ID:	35391567
Organisation:	Ministry of Education - School Infrastructure
Open date:	Thursday, 5 November 2026 9:00 AM +13:00
Close date:	Saturday, 12 December 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for Glenavon School (the School) – Blocks 1, 3, 4, 8: Roof Works – Main Building Contractor (the Contract Works).

Main Contractor for the Blocks 1, 4, 5, 6, 8: Roofing and Ceiling Tile Works at Oteha Valley School

Ministry of Education - School Infrastructure — Wed, 04 Nov 2026 20:00:00 GMT

RFx ID:	35390478
Organisation:	Ministry of Education - School Infrastructure
Open date:	Thursday, 5 November 2026 9:00 AM +13:00
Close date:	Saturday, 12 December 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for Oteha Valley School (the School) – Blocks 1, 4, 5, 6, 8: Roofing and Ceiling Tile Works – Main Building Contractor (the Contract Works).

Main Contractor for the Blocks 2, 3, 4, 8: Replace Failed Door Ranch Sliders and Window Winders at Oteha Valley School

Ministry of Education - School Infrastructure — Wed, 04 Nov 2026 20:00:00 GMT

RFx ID:	35390224
Organisation:	Ministry of Education - School Infrastructure
Open date:	Thursday, 5 November 2026 9:00 AM +13:00
Close date:	Saturday, 12 December 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for Oteha Valley School (the School) – Blocks 2, 3, 4, 8: Replace Failed Door Ranch Sliders and Window Winders – Main Building Contractor (the Contract Works).

Main Contractor for the Block 2: Toilet Refurbishment at Northcross Intermediate School

Ministry of Education - School Infrastructure — Tue, 03 Nov 2026 20:00:00 GMT

RFx ID:	35371117
Organisation:	Ministry of Education - School Infrastructure
Open date:	Wednesday, 4 November 2026 9:00 AM +13:00
Close date:	Saturday, 12 December 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for Northcross Intermediate School (the School) – Block 2: Toilet Refurbishment – Main Building Contractor (the Contract Works).

Main Contractor for the Block Temp: Classroom Refurbishment and Removal of ACM Cladding at Northcross Intermediate School

Ministry of Education - School Infrastructure — Tue, 03 Nov 2026 20:00:00 GMT

RFx ID:	35370890
Organisation:	Ministry of Education - School Infrastructure
Open date:	Wednesday, 4 November 2026 9:00 AM +13:00
Close date:	Saturday, 12 December 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for Northcross Intermediate School (the School) – Block Temp: Classroom Refurbishment and Removal of ACM Cladding – Main Building Contractor (the Contract Works).

Main Contractor for the Blocks 2, 11: Re-aligning classroom walls, Removal of ACM cladding, and Classroom Refurbishment at Northcross Intermediate School

Ministry of Education - School Infrastructure — Tue, 03 Nov 2026 20:00:00 GMT

RFx ID:	35370576
Organisation:	Ministry of Education - School Infrastructure
Open date:	Wednesday, 4 November 2026 9:00 AM +13:00
Close date:	Saturday, 12 December 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for Northcross Intermediate School (the School) – Blocks 2, 11: Re-aligning classroom walls, Removal of ACM cladding, and Classroom Refurbishment – Main Building Contractor (the Contract Works).

Main Contractor for the Site: Carpark, Footpaths and Bus Shelter at Northcross Intermediate School

Ministry of Education - School Infrastructure — Tue, 03 Nov 2026 20:00:00 GMT

RFx ID:	35370395
Organisation:	Ministry of Education - School Infrastructure
Open date:	Wednesday, 4 November 2026 9:00 AM +13:00
Close date:	Saturday, 12 December 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for Northcross Intermediate School (the School) – Site: Carpark, Footpaths and Bush Shelter – Main Building Contractor (the Contract Works).

RFT for a Main Contractor for a new Hall for Chelsea Primary School

Ministry of Education - School Infrastructure — Mon, 26 Oct 2026 20:30:00 GMT

RFx ID:	34976626
Organisation:	Ministry of Education - School Infrastructure
Open date:	Tuesday, 27 October 2026 9:30 AM +13:00
Close date:	Monday, 7 December 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	The School is planning to undertake these works. Refer to the RFT for detail on the scope of works and for site visit information.

Te Kura o Hirangi - Building Block A,D,E,F: Toilet, ceiling and deck replacement

Ministry of Education - School Infrastructure — Fri, 06 Nov 2026 01:00:00 GMT

RFx ID:	35428734
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 6 November 2026 2:00 PM +13:00
Close date:	Saturday, 5 December 2026 5:00 PM +13:00
Categories:	72121400 - Specialized public building construction services
Region:	Bay of Plenty
Overview:	The Scope of the project is based on the interviews with Kura teachers and staff and a Condition Assessment undertaken on behalf of the Kura for all the buildings highlighting various potential upgrades and improvements to keep the buildings compliant, safe and in good condition for the next life cycle of the buildings. o Outcome sought – Maximum amenity from the Kura’s buildings, compliance and necessary replacements o History - School buildings require regular maintenance for optimum function and enjoyment

Main Contractor for Block E (Music Suite) Roof & Wall Recladding at Maruawai College

Ministry of Education - School Infrastructure — Sun, 01 Nov 2026 20:00:00 GMT

RFx ID:	35354409
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 2 November 2026 9:00 AM +13:00
Close date:	Thursday, 3 December 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Southland
Overview:	The Maruawai College Board of Trustees is looking for an experienced main Contractor to complete exterior refurbishment work including roof, wall cladding & window replacements at their Block E Music Suite block. Work also includes fire compliance upgrade works and associated make good reinstatement. The work is a continuation and similar in scope to the Blocks B,D,F work completed previously.

RFT for Main Contractor for Fire Alarm Replacement at Te Kamo High School

Ministry of Education - School Infrastructure — Tue, 03 Nov 2026 20:00:00 GMT

RFx ID:	35386048
Organisation:	Ministry of Education - School Infrastructure
Open date:	Wednesday, 4 November 2026 9:00 AM +13:00
Close date:	Tuesday, 1 December 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Northland
Overview:	The existing fire alarm system installed across the school has a number of obsolete components that are no longer available. As the units are failing, they are causing a number of costly nuisance alarms and incurring call out fees. Stage 1 of the site wide upgrade has already been completed. This included the installation of a new fire panel in the admin building and replacement of the fire alarm system in the admin building with a new Type 4 alarm system. Stage 2 involves as the further upgrade of all remaining buildings on site from the obsolete fire alarm system to a new compatible Type 4 system.

RFT - Civil Works Contractor for Site - Drainage at Ōtaki College, Ōtaki, Kāpiti Coast

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35343823
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Tuesday, 1 December 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Manawatu-Wanganui Wellington
Overview:	Aging and inefficient stormwater drainage infrastructure across the site is regularly struggling to cope with water disposal in periods of heavy rainfall. A specialist civil engineer has investigated the site and developed a detailed scope of work including the replacement of sumps, underground pipework, the introduction of new soak pits, upgrading existing manholes and general improvement of surface water capture and disposal. The project also incorporates the targeted renewal of concrete pavements and roadways. This work is to be priced separately but would be delivered in conjunction with the drainage improvements. Project approval application will be presented across the two NZSPA projects.

RFT - Main Building Contractor for LSM Block D - Access, Security, Sensory at Wainuiomata High School, Wainuiomata, Lower Hutt

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35346974
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Monday, 30 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Manawatu-Wanganui Wellington
Overview:	This project has originated from an Occupational Therapist’s recommendation report highlighting a number of shortcomings within the school’s learning support facility which has areas and components not fit for purpose. The scope consists of security upgrades to the existing doors leading into the facility, various sensory space improvements and the conversion of one of the nearby offices into a dysregulation space.

Main Contractor for Southland Boys' High School - Pearce Block Steel Window Replacement

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 21:30:00 GMT

RFx ID:	35347833
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 10:30 AM +13:00
Close date:	Monday, 30 November 2026 4:00 PM +13:00
Categories:	The United Nations Standard Products and Services Code (UNSPSC)
Region:	Southland
Overview:	During planning for the Block A major roof replacement in 2023, it was identified that the north-side steel windows were in significant disrepair. The school had intended to carry out cyclical maintenance painting while scaffolding was in place for the roof works. However, following investigations and a subsequent Condition Assessment Report it was confirmed that many of the steel frames had degraded to such an extent that steel had delaminated, resulting in failure to operate, poor weathertightness, and reduced energy efficiency. As this is a listed historical building, Heritage New Zealand were engaged, who confirmed and validated the assessment findings, advising that in-situ repair was no longer viable. In consultation with Heritage NZ, agreement was reached to replace the existing units with aluminium-framed, double-glazed windows designed to replicate the original steel windows. To preserve the façade’s heritage character (Heritage NZ Class 2), the solution incorporates false set aluminium colonial bars to maintain the original appearance while providing durability, weathertightness, and compliance with New Zealand Building Code energy efficiency standards. This project is critical to prevent ongoing heat loss, moisture ingress, and consequential damage to the building fabric. In addition to the above it may be necessary to stage or phase the works to the façade in order to not or at least minimize intrusion into the schools’ activities as little as possible. The Contract Works required are: i. Demolition of existing steel framed windows ii. Installation of new aluminium framed windows iii. Making good interior and exterior surrounding plaster and linings The extent of the contract works area encompasses the entire northern façade of Pearce Block, excluding only the existing central, curved, aluminium framed joinery unit.

Main Contractor for Roofing Refurbishment at Avalon School (Wellington)

Ministry of Education - School Infrastructure — Sun, 01 Nov 2026 20:00:00 GMT

RFx ID:	35356936
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 2 November 2026 9:00 AM +13:00
Close date:	Friday, 27 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Wellington
Overview:	2.1 Background a. Avalon Primary School is undertaking roof replacement and associated remediation works to Blocks 1, 2, 3, 5 and 10. This may include: i. General Description: The project will replace end-of-life and deteriorated roof areas to provide a safer, durable and fit-for-purpose roofing solution. The roofing specialist report identified these areas as being at or near the end of their serviceable life. A subsequent scoping inspection confirmed widespread deterioration and the need for replacement and remediation ii. Outcome sought: The outcome sought is to replace the end-of-life and deteriorated roofing across Blocks 1, 2, 3, 5 and 10 at Avalon Primary School, providing durable, weathertight roofing that protects the buildings and supports a safe learning environment, while minimising disruption to school operations. iii. History: A 10YPP specialist report identified significant condition and weathertightness issues. This project is included in the current 5YA programme. iv. Overview of the programme of which this project is a part: The works form part of the School’s current 5YA programme and are funded from 5YA and 5YA supplementary funding. v. requirements for phasing and / or staged handover of the project: The roofing replacement works to Blocks 1, 2, 3, 5 and 10 will need to be staged and coordinated with the school to minimise disruption to teaching and maintain safe school operations throughout construction. The contractor will agree the sequencing, work areas and any temporary access restrictions with the school before commencing works. Each completed area must be weather-tight, safe and cleared of construction materials before being handed back for school use. vi. Project consultants are: a. Project Manager: Milla Saris - Ruruku b. Lead Designer: Griffin Tozer - Ruruku

RFT - Main Building Contractor for Kimi Ora Satellite (Block A - Partial Rationalisation) at Pōmare School, Taita, Lower Hutt

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35344920
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Thursday, 26 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Manawatu-Wanganui Wellington
Overview:	The entire western wing of Block A at Pōmare School is surplus to requirements and is over the school’s footprint entitlement. NZSPA has approved funding and it has been agreed to demolish this wing of Block A together with the necessary disconnection and capping off plumbing and electrical services A new concrete ramp and area of asphalt paving is proposed to improve accessibility to the altered west facing end of the building Other carpentry works required within the proposed contract will incorporate wall and roof framing modifications, new timber weatherboard cladding and painting

RFT - Main Roofing Contractor for Blocks A, B - Roofing and Downpipe Replacement at Dyer Street School, Epuni, Lower Hutt

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35344363
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Thursday, 26 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Manawatu-Wanganui Wellington
Overview:	The current 5YA has funding allocated to address the replacement of end of life roofing components on two buildings. The scope consists of: - Replacement pre finished metal roofing to both ends of Block B (hall) - This work will incorporate the relocation of heat pump outdoor units to the ground - Partial metal roofing and installation of improved pipe penetration flashings is required at the western end of Block A - Three areas of translucent polycarbonate roofing on Block A also require renewal - Where metal roofing is replaced and access to the ceiling void is available thermal insulation batts will be introduced

ROI - Drainage Contractor for Kaipara College - Site: Drainage Remediation

Ministry of Education - School Infrastructure — Tue, 03 Nov 2026 20:00:00 GMT

RFx ID:	35355374
Organisation:	Ministry of Education - School Infrastructure
Open date:	Wednesday, 4 November 2026 9:00 AM +13:00
Close date:	Wednesday, 25 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	CCTV inspection of all stormwater lines from site drainage to public outlet and damaged sewer line. Replace damaged section of sewer line, raise existing inspection chamber lid to suit finished ground level, and supply/install a new lid outside Reception area. Supply, install, and connect a new gully trap, including all associated drainage works and reinstatement for kitchen sinks in Block Remove and replace approx. 40m of stormwater channel in area outside Block D. Repair of existing stormwater drains and retention tanks, and verify/reinstate the connection to the public stormwater network in area around Block G.

Bayswater School - Main Contractor for 1, 2, 3, 5, 100636, site: Full Roof Replacements, fixings, and Clearlite roofing.

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 01:00:00 GMT

RFx ID:	35337103
Organisation:	Ministry of Education - School Infrastructure
Open date:	Thursday, 29 October 2026 2:00 PM +13:00
Close date:	Wednesday, 25 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	Bayswater School is seeking a suitably experienced and qualified contractor to undertake roof remediation, and replacement works across Blocks 1, 2, 3, 5, 100636 (Hall), and associated site structures. The project includes replacement of deteriorated roofing elements, roof fixings, gutters, clearlite roofing and safety mesh installations, together with covered way roof replacement and updating of the school's CAD site plan. Works will be undertaken within a live operational school environment and will require careful coordination to minimise disruption to school activities.

Verran Primary School - Main Contractor for 1, 2, 3, 4, 6, 9, 11: Roofing

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 00:00:00 GMT

RFx ID:	35336865
Organisation:	Ministry of Education - School Infrastructure
Open date:	Thursday, 29 October 2026 1:00 PM +13:00
Close date:	Wednesday, 25 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	The School Board seeks registrations from suitably qualified contractors for roofing renewal works across multiple buildings at Verran Primary School. The project includes roofing replacement, flashings, gutters, downpipes, clearlite roofing and associated remedial works. Contractors should demonstrate experience delivering roofing projects within occupied educational facilities and managing working-at-height activities. Shortlisted contractors will be invited to participate in a subsequent Request for Tender process.

Verran Primary School - Drain Laying Works for 6, 11, Site: Plumbing and Drainage – Plumbing and Drainage Works

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 00:30:00 GMT

RFx ID:	35336657
Organisation:	Ministry of Education - School Infrastructure
Open date:	Thursday, 29 October 2026 1:30 PM +13:00
Close date:	Wednesday, 25 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	The School Board seeks registrations from suitably qualified contractors for drainage, plumbing and associated infrastructure works at Verran Primary School. The project includes drainage investigations, drainage renewal works, drinking fountain upgrades, water tank replacement and associated civil works. Contractors should demonstrate experience delivering underground services and infrastructure projects within occupied school environments. Shortlisted contractors will be invited to participate in a subsequent Request for Tender process.

Verran Primary School - Main Contractor for Covered Ways Demo, Alarm Replacements & Gas Decommissioning

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 00:30:00 GMT

RFx ID:	35336470
Organisation:	Ministry of Education - School Infrastructure
Open date:	Thursday, 29 October 2026 1:30 PM +13:00
Close date:	Wednesday, 25 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	The School Board seeks registrations from suitably qualified contractors for site infrastructure and services upgrade works at Verran Primary School. The project includes covered walkway demolition, fire alarm replacement, security alarm replacement, gas decommissioning and associated underground services works. Contractors should demonstrate experience delivering infrastructure, fire, security and underground services projects within occupied educational environments. Shortlisted contractors will be invited to participate in a subsequent Request for Tender process.

Main Building Contractor for AMS Upgrade & Refurbishment to Block 1 at Winchester Street School

Ministry of Education - School Infrastructure — Sun, 18 Oct 2026 20:00:00 GMT

RFx ID:	35234986
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 9:00 AM +13:00
Close date:	Wednesday, 25 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Manawatu-Wanganui
Overview:	The Contract Works required are: The proposal is to refurbish and reconfigure Block 1 classrooms on the northern and southern wings. This will include new carpet tiles and wall linings. Reconfiguration will involve removing some store rooms to create a larger classroom 9, making the breakout space layouts more fit for purpose and correcting fire and accessibility issues in the hall. All work to comply with manufacturer’s specifications and recommendations. All tender documentation and necessary information attached. Contractors MUST visit site for tender to be compliant. Contact the noted representative in Invite Letter to arrange a site visit. Ideally dependent on MoE funding approval this work would start as soon as possible after confirmation provided, however this will be discussed with the successful contractor and school once funding approvals are confirmed. TERMS AND CONDITIONS: https://education.govt.nz/assets/Documents/Primary-Secondary/Property/Procurement-templates-guides/School-Property-Procurement-RFx-Process-Terms-Conditions-Conditions-of-Tendering-2017-2.pdf

Main Contractor for Gymnasium Floor Replacement at Clutha Valley School

Ministry of Education - School Infrastructure — Wed, 28 Oct 2026 03:00:00 GMT

RFx ID:	35332318
Organisation:	Ministry of Education - School Infrastructure
Open date:	Wednesday, 28 October 2026 4:00 PM +13:00
Close date:	Tuesday, 24 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Otago Southland
Overview:	This Request for Tenders (RFT) is an open invitation to Contractors to submit a Tender for Clutha Valley School – Gymnasium Floor Replacement – Structural Floor Works (Demolition of Suspended Timber Floor and New Concrete Slab-on-Ground).

TKKM o Kawakawa mai Tawhiti - Gym Floor Replacement - Main Contractor Services

Ministry of Education - School Infrastructure — Tue, 27 Oct 2026 20:00:00 GMT

RFx ID:	35331493
Organisation:	Ministry of Education - School Infrastructure
Open date:	Wednesday, 28 October 2026 9:00 AM +13:00
Close date:	Tuesday, 24 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Bay of Plenty Gisborne
Overview:	This Request for Tenders (RFT) issued by NZSPA (the Principal to the Contract) in an invitation to qualified suppliers to submit a Tender for TKKM o Kawakawa mai Tawhiti - Gym Floor Replacement - Main Contractor Works.

RFT - Main Building Contractor for Blocks 1, 3, 14, T1 - Roof Remediation and Timber Joinery Replacement at Newlands Primary School, Newlands, Wellington

Ministry of Education - School Infrastructure — Mon, 19 Oct 2026 04:00:00 GMT

RFx ID:	35236220
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 5:00 PM +13:00
Close date:	Monday, 23 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Manawatu-Wanganui Wellington
Overview:	Specialist reports have identified degraded metal roofing and timber windows which are to be replaced to various buildings at Newlands Primary School. The roofing work focuses on Block 1 replacing the flat metal roofing which includes replacing the clerestory windows to ensure compliant upstands and clearances are provided. The clear roofing to Block 14 is to be replaced with a trafficable product over mesh and an eave flashing is to be fitted to Block T1. Timber windows will be replaced to Blocks 1 and 3 along with any rotten timber cladding encountered. The work is extensive across an active school site for which a well considered site management plan is required to ensure risk to normal school operations are minimalised.

Main Building Contractor - 1, 5,7: Roofing and Learning Space Upgrade at Tainui School

Ministry of Education - School Infrastructure — Thu, 22 Oct 2026 20:00:00 GMT

RFx ID:	35289813
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 23 October 2026 9:00 AM +13:00
Close date:	Friday, 20 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Otago
Overview:	Block 7 ● Replace exterior windows and doors ● New deck & veranda ● Replace translucent roofing on existing veranda. ● New Joinery units ● New wall finishes. Block 5 ● Replace floor coverings Block 1 ● Replace Door

Main Building Contractor – E: Redevelopment at Queenstown Primary School

Ministry of Education - School Infrastructure — Thu, 22 Oct 2026 20:00:00 GMT

RFx ID:	35288235
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 23 October 2026 9:00 AM +13:00
Close date:	Friday, 20 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Otago Southland
Overview:	The Contract Works comprise the full renewal of the building envelope and teaching spaces of Block E. This includes removing the existing roofing and asbestos cladding and replacing them with new Colorsteel roofing and James Hardie Axon cavity cladding, replacing all joinery with thermally broken aluminium glazing, and installing new underfloor insulation with subfloor repairs and repiling of approximately six piles. New air conditioning units and stairs will be installed, and the internal linings, ceilings, lighting and flooring in both classrooms will be renewed, with the existing acoustic panels reinstated.

Ashburton Borough School - Lagmhor Site - Water Supply Infrastructure Upgrade - Main Contractor

Ministry of Education - School Infrastructure — Tue, 20 Oct 2026 22:00:00 GMT

RFx ID:	35282833
Organisation:	Ministry of Education - School Infrastructure
Open date:	Wednesday, 21 October 2026 11:00 AM +13:00
Close date:	Friday, 20 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Canterbury
Overview:	This Request for Tenders (RFT) issued by Savills (NZ) Limited, on behalf of NZSPA, is an open invitation to contractors to submit a tender for ABS - Lagmhor Site - Water Infrastructure Upgrade - Main Contractor Services.

Drainage Contractor for A, G, J: Drainage Works – New Cesspits, Sump, Chamber & Channel Drain at Wairoa College

Ministry of Education - School Infrastructure — Wed, 21 Oct 2026 20:00:00 GMT

RFx ID:	35278810
Organisation:	Ministry of Education - School Infrastructure
Open date:	Thursday, 22 October 2026 9:00 AM +13:00
Close date:	Friday, 20 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Gisborne Hawke's Bay
Overview:	Wairoa College Board of Trustees wishes to engage a suitably qualified drainage contractor to complete site wide remediation of drainage issues and installation of new cesspits/channel drains etc

Main Contractor for Wall Lining Remediation and Floor Covering & Acoustic Wall Covering Installation at Takapau School

Ministry of Education - School Infrastructure — Wed, 21 Oct 2026 20:00:00 GMT

RFx ID:	35278659
Organisation:	Ministry of Education - School Infrastructure
Open date:	Thursday, 22 October 2026 9:00 AM +13:00
Close date:	Friday, 20 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Hawke's Bay
Overview:	Takapau School Board of Trustees wishes to engage a main contractor for the remediation of internal wall linings and the replacement of end of life floor coverings and installation of acoustic wall coverings.

Main Building Contractor for Toilet Refurbishment Project at Tamatea Intermediate

Ministry of Education - School Infrastructure — Wed, 21 Oct 2026 04:00:00 GMT

RFx ID:	35260322
Organisation:	Ministry of Education - School Infrastructure
Open date:	Wednesday, 21 October 2026 5:00 PM +13:00
Close date:	Friday, 20 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Hawke's Bay
Overview:	Tamatea Intermediate Board of Trustees are seeking a main building contractor for the Refurbishment of two toilet blocks almost identical in layout including new windows, taller cubicles, new fixtures and fittings, new floor linings and wall and ceiling finishes.

Main Building Contractor for Indoor Outdoor Learning Project at Onekawa School

Ministry of Education - School Infrastructure — Tue, 20 Oct 2026 20:00:00 GMT

RFx ID:	35259932
Organisation:	Ministry of Education - School Infrastructure
Open date:	Wednesday, 21 October 2026 9:00 AM +13:00
Close date:	Friday, 20 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Hawke's Bay
Overview:	Onekawa School Board of Trustees are seeking a main building contractor for three Indoor Outdoor learning areas including three roofing and decking structures and replacement of windows with doors providing external access to decks.

Main Contractor for Thorndon School (Wellington) A, B & C: Combined AMS 5YA Covered Outdoor Learning Area (COLA)

Ministry of Education - School Infrastructure — Wed, 07 Oct 2026 20:00:00 GMT

RFx ID:	35084227
Organisation:	Ministry of Education - School Infrastructure
Open date:	Thursday, 8 October 2026 9:00 AM +13:00
Close date:	Friday, 20 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Wellington
Overview:	The project comprises the construction of a new permanent Covered Outdoor Learning Area (COLA) at Thorndon School, with a suitably experienced main contractor sought to deliver the complete works in accordance with the architectural, structural and associated tender documentation. The works include the engineered timber structure, translucent roofing, associated rainwater goods and drainage connections, hard and soft landscaping, reinstatement and all ancillary works necessary to provide a complete solution. The preferred outcome is a durable, compliant and fit-for-purpose covered outdoor learning space that maximises the use of the school's constrained inner-city site and provides a safe, weather-protected area for teaching, gathering and general school use throughout the year. Contractors are expected to demonstrate a robust methodology, appropriate resourcing and a practical programme that manages cost, quality and programme risk while delivering the works in accordance with the architectural and engineered design. The structural design incorporates engineered glulam beams, columns and purlins together with specifically detailed connections. Given the scale of the works, the project is likely to extend into school term time, making programme management and health and safety crucial considerations. The contractor will need to maintain safe separation between construction activities and students, staff and visitors, while carefully managing access, deliveries, noise, dust and disruption to normal school operations. The preferred programme currently anticipates commencement in December 2026 and completion by April 2027, although alternative programmes may be considered. Subject to the level of tender responses received and available budget, the project may also be split into two phases, with staging and sequencing therefore forming an important part of the contractor's proposed approach.

Main Roofing Contractor for gym roofing replacement at Heretaunga College

Ministry of Education - School Infrastructure — Thu, 22 Oct 2026 22:00:00 GMT

RFx ID:	35276619
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 23 October 2026 11:00 AM +13:00
Close date:	Friday, 20 November 2026 11:00 AM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Wellington
Overview:	The Heretaunga College Board of Trustees are seeking a suitably experienced, capable, and resourced Roofing Contractor with experience on school projects of a similar nature to replace the Gym roof and two small translucent verandah roofs as described in detail in "2.2 Required solution (the Contract Works)" in the the Request for Tender attached. The works are required to be completed prior to Term 1 2027.

Main Contrcator for the Blocks 1A, 1B, 2, 3, 5, 6, 8, A,M, N, S, R: Roofing Works at Hillpark School

Ministry of Education - School Infrastructure — Wed, 21 Oct 2026 20:00:00 GMT

RFx ID:	35266006
Organisation:	Ministry of Education - School Infrastructure
Open date:	Thursday, 22 October 2026 9:00 AM +13:00
Close date:	Thursday, 19 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:

RFT - Main Contractor for Plumbing & Toilet Project at Chapel Downs School

Ministry of Education - School Infrastructure — Mon, 19 Oct 2026 20:00:00 GMT

RFx ID:	34970352
Organisation:	Ministry of Education - School Infrastructure
Open date:	Tuesday, 20 October 2026 9:00 AM +13:00
Close date:	Thursday, 19 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	Main Building Contractor required for bathroom refurbishment works Primary School is located SE Auckland in Flat Bush Carpentry, Plumbing, electrical, vinyl flooring are the main trades Consent has been applied for main toilet refurbishment with additional pans to install, wall and door changes - for more details see drawings Additional minor toilet works may be required Special Needs Toilet works need to be completed for return of students term 1 2027

Dargaville High School – Pool Roof Replacement

Ministry of Education - School Infrastructure — Mon, 19 Oct 2026 20:00:00 GMT

RFx ID:	35230016
Organisation:	Ministry of Education - School Infrastructure
Open date:	Tuesday, 20 October 2026 9:00 AM +13:00
Close date:	Thursday, 19 November 2026 12:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Northland
Overview:	The Contract Works require: - Demolition of the existing ridge pop-up vent along the full pool hall ridge (approx. 28.9 m), with careful removal, storage and reinstatement of the aluminium louvres. Removal of the existing roofing underlay accessible between the trusses, with edges taped to stop debris entering the pool. - Structural remediation to all existing roof trusses to BG&E's design: steel strap bracing, timber struts, a continuous apex tie, and repair or replacement of truss connector plates with plywood gussets. Replacement of the roof purlins. - A new engineered timber-framed ridge pop-up structure. - New roofing to the pop-up only: pressed metal roof tiles to match existing, flashings, fibre cement cladding on rigid air barrier, fascia, barge boards, soffits and underlay. - New box gutters and uPVC downpipes along both sides of the full roof length. - Repaint of all exposed roof framing and existing truss connector plates. - Hold points for asbestos sampling of the pop-up (any removal by Variation at tendered rates) and BG&E construction monitoring inspections. The main roof underlay is not being renewed and the existing internal box gutters are retained and cleaned only. The pool building is approx. 450 m². Works are under Building Consent Exemption EX260300 (Kaipara District Council). The pool will be out of service during the works and may need to be drained; pool plant and equipment must be protected and the enclosure kept weathertight.

Elmwood Normal School - Demolition - Main Contract Works

Ministry of Education - School Infrastructure — Wed, 21 Oct 2026 02:00:00 GMT

RFx ID:	35282044
Organisation:	Ministry of Education - School Infrastructure
Open date:	Wednesday, 21 October 2026 3:00 PM +13:00
Close date:	Wednesday, 18 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Canterbury
Overview:	Elmwood Normal School is a State Contributing Normal school situated in beautiful grounds in the central city suburb of Merivale, Christchurch. It offers a six-year programme, catering for Years 0–6 children, from which the children then proceed to intermediate schools. CSR rebuild works have now been completed with new two-storey blocks being constructed. The old two blocks are now to be removed as they are surplus to requirements. School is still deciding on how to best utilise the cleared space but at this stage the expectation is for the site to be left hard compacted and safe. Should any further works be required this will be negotiated during construction

Kelston Intermediate: Main Contractor for Block 3 Refurbishment

Ministry of Education - School Infrastructure — Wed, 21 Oct 2026 00:30:00 GMT

RFx ID:	35277379
Organisation:	Ministry of Education - School Infrastructure
Open date:	Wednesday, 21 October 2026 1:30 PM +13:00
Close date:	Wednesday, 18 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	Full refurbishment of two classrooms (Rooms 13 and 14), Block 3, Kelston Intermediate School, 300 Vanguard Road, Kelston, Auckland. Works include: demolish classrooms to floor joists; replace sub-floor framing as required; H3 ply-floor; new wall framing, trusses, and roof framing; new roofing, spouting, and JH Linea cladding; aluminium double-glazed joinery throughout; insulation and plasterboard lining with Autex Composition; reinstated toilet and special needs room; suspended acoustic ceilings to MoE requirements; reinstatement of electrical, fire, security, and data services. Asbestos removal to be carried out by licensed specialist sub-contractor (Class B or C as required).

Mt Albert School Site: Asphalt Re-surfacing

Ministry of Education - School Infrastructure — Tue, 20 Oct 2026 23:30:00 GMT

RFx ID:	35274890
Organisation:	Ministry of Education - School Infrastructure
Open date:	Wednesday, 21 October 2026 12:30 PM +13:00
Close date:	Wednesday, 18 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	upgrade the main playing area with new asphalt surfacing to provide a safe, durable and low-maintenance outdoor space for student use, improving the functionality and usability of the area.

Mt Albert School: Main Contractor For Blocks 1,3,6,Temp2,Temp4,Temp5: Roofing

Ministry of Education - School Infrastructure — Tue, 20 Oct 2026 23:30:00 GMT

RFx ID:	35273948
Organisation:	Ministry of Education - School Infrastructure
Open date:	Wednesday, 21 October 2026 12:30 PM +13:00
Close date:	Wednesday, 18 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	Request for Tenders for Mt Albert Primary School (the School) – Roof and Roof Parts Replacement, Roof Repairs & AC Mounts (Blocks 1, 3, 6, A, Temp 2, Temp 4 & Temp 5) – Roofing Repairs and Replacement

Main Contractor for the Blocks A, H, L, M, N, S, T: Boiler Roofing and Site CAD Plan at Mangere College

Ministry of Education - School Infrastructure — Tue, 20 Oct 2026 21:00:00 GMT

RFx ID:	35267774
Organisation:	Ministry of Education - School Infrastructure
Open date:	Wednesday, 21 October 2026 10:00 AM +13:00
Close date:	Wednesday, 18 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:

Main Contractor for the Blocks A D H L M N S 5: Heating and Switchboards Upgrade at Mangere College

Ministry of Education - School Infrastructure — Tue, 20 Oct 2026 20:00:00 GMT

RFx ID:	35259357
Organisation:	Ministry of Education - School Infrastructure
Open date:	Wednesday, 21 October 2026 9:00 AM +13:00
Close date:	Wednesday, 18 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:

Request for Tenders for Dargaville Primary School – Block 3 Hall – Reclad and Accessible Ramp

Ministry of Education - School Infrastructure — Mon, 19 Oct 2026 20:00:00 GMT

RFx ID:	35219149
Organisation:	Ministry of Education - School Infrastructure
Open date:	Tuesday, 20 October 2026 9:00 AM +13:00
Close date:	Wednesday, 18 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Northland
Overview:	The Contract Works require: - Removal and disposal of the existing external wall cladding, cover battens, flashings, window joinery and subfloor baseboards, including removal of any asbestos-containing materials by a WorkSafe licensed asbestos removalist, with clearance certification. - Removal, storage and reinstatement of the existing external doors with new jamb liners and trims. - Demolition of the existing entrance ramp. - Inspection of the exposed wall framing and remediation of any damaged or decayed framing (Provisional Sum and Schedule of Rates). - Installation of a rigid air barrier, drained timber cavity battens and James Hardie Stria fibre cement cladding (installed vertically), with all associated flashings, trims and paint finish, to E2/AS1 and the manufacturer's requirements. - New powder-coated aluminium window joinery to the existing openings (W01 to W11). - New timber subfloor cladding and subfloor access door. - New spouting and downpipes where shown. - Removal and reinstatement of the external air conditioning outdoor unit to suit the new cladding. - New accessible timber ramp, stairs and balustrades with concrete landing and foundations to the structural engineer's design. - Type 4 fire alarm, emergency lighting and exit signage to the Fire Safety Compliance Report (contractor design and build, Provisional Sum). - Making good and site reinstatement. - Asbestos removal and other noisy work must happen during the summer school holidays, and the hall can’t be used while the work is under way. The hall is approximately 236 m², single storey, at 21 Portland Street, Dargaville. Works are single stage, with handover of the whole hall at Practical Completion. Internal alterations, internal lining repairs and roof or soffit extensions are excluded.

Main Contractor for Fencing Project at Te Pi'ipi'inga Kākano Mai I Rangiātea Kura

Ministry of Education - School Infrastructure — Tue, 20 Oct 2026 19:00:00 GMT

RFx ID:	35236594
Organisation:	Ministry of Education - School Infrastructure
Open date:	Wednesday, 21 October 2026 8:00 AM +13:00
Close date:	Wednesday, 18 November 2026 4:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Taranaki
Overview:	This RFT is for a main contractor to complete a Learning Support Modification Fencing project at Te Pi'ipi'inga Kakano Mai I Rangiātea.

Main Contractor for Internal Alteration at Tuakau College

Ministry of Education - School Infrastructure — Mon, 19 Oct 2026 21:00:00 GMT

RFx ID:	35241295
Organisation:	Ministry of Education - School Infrastructure
Open date:	Tuesday, 20 October 2026 10:00 AM +13:00
Close date:	Tuesday, 17 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	Internal alterations to a classroom to change it into a food technology clasroom. Works include demolition of existing interior finishes and fittings, construction of new doorways, filling in existing doorways, new cabinet fittings, new flooring, new electrical and plumbing layouts and a new extract ventilation system.

Roofing Contractor for Blocks A,B,F,G,I & J Roofing Replacement at Pirinoa School (Wairarapa)

Ministry of Education - School Infrastructure — Mon, 19 Oct 2026 03:00:00 GMT

RFx ID:	35233759
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 4:00 PM +13:00
Close date:	Tuesday, 17 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Manawatu-Wanganui Wellington
Overview:	The Pirinoa School Board of Trustees seeks the services of a Roofing Contractor to undertake the replacement of existing metal roof coverings to Blocks A, B, F, G, I and J. The works include the removal and disposal of existing roofing materials, flashings and fixings; inspection of the roof substrate and minor repairs as required; installation of new long-run metal roofing, flashings, penetrations, insulation and vented battens where practical; replacement of associated spouting; and connection of spouting outlets to the existing downpipe system

Main Contractor for the Block 13: Food Tech Upgrade at St Thomas School

Ministry of Education - School Infrastructure — Sun, 18 Oct 2026 20:00:00 GMT

RFx ID:	35227778
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 9:00 AM +13:00
Close date:	Tuesday, 17 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for St Thomas School (the School) – Block 13: Food Tech Upgrade – Main Building Contractor (the Contract Works).

Main Contractor for the Block 14: Intumescent Paint at St Thomas School

Ministry of Education - School Infrastructure — Sun, 18 Oct 2026 20:00:00 GMT

RFx ID:	35227714
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 9:00 AM +13:00
Close date:	Tuesday, 17 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for St Thomas School (the School) – Block 14: Intumescent Paint – Main Building Contractor (the Contract Works).

Main Contractor for the Blocks 3, 5,14: Window Winder and Louvre, Door Mechanism and ILE Sliding Door Remediation +Window Replacement at St Thomas School

Ministry of Education - School Infrastructure — Sun, 18 Oct 2026 20:00:00 GMT

RFx ID:	35227577
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 9:00 AM +13:00
Close date:	Tuesday, 17 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for St Thomas School (the School) – Blocks 3, 5,14: Window Winder and Louvre, Door Mechanism and ILE Sliding Door Remediation +Window Replacement – Main Building Contractor (the Contract Works).

Main Contractor for the Blocks 12, 14: Wall Covering Replacement + Carpet Replacement at St Thomas School

Ministry of Education - School Infrastructure — Sun, 18 Oct 2026 20:00:00 GMT

RFx ID:	35227383
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 9:00 AM +13:00
Close date:	Tuesday, 17 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for St Thomas School (the School) – Blocks 12, 14: Wall Covering Replacement + Carpet Replacement – Main Building Contractor (the Contract Works).

Main Contractor for the Blocks 3, 11, 15: DQLS Replacement, Toilet Refurbishment (1x) + Reconfigure shared toilet into separate staff toilet and a unisex toilet at St Thomas School

Ministry of Education - School Infrastructure — Sun, 18 Oct 2026 20:00:00 GMT

RFx ID:	35227242
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 9:00 AM +13:00
Close date:	Tuesday, 17 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for St Thomas School (the School) – Blocks 3, 11, 15: DQLS Replacement, Toilet Refurbishment (1x) + Reconfigure shared toilet into separate staff toilet and a unisex toilet – Main Building Contractor (the Contract Works).

Main Contractor for the Blocks 1B, 2, 3, 5, 8, 9, 10, 11, 12, 13, 14, 19, Pool: Roofing Works at St Thomas School

Ministry of Education - School Infrastructure — Sun, 18 Oct 2026 20:00:00 GMT

RFx ID:	35227094
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 9:00 AM +13:00
Close date:	Tuesday, 17 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for St Thomas School (the School) – Blocks 1B, 2, 3, 5, 8, 9, 10, 11, 12, 13, 14, 19, Pool: Roofing Works – Main Building Contractor (the Contract Works).

Main Contractor for the Blocks 1A, 7, 8A: Roof Works (Roof Parts, Clearlite, Gutter and AC Mounts Replacement, and Remediation) at Glendowie Primary School

Ministry of Education - School Infrastructure — Sun, 18 Oct 2026 20:00:00 GMT

RFx ID:	35226228
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 9:00 AM +13:00
Close date:	Tuesday, 17 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for Glendowie Primary School (the School) – Blocks 1A, 7, 8A: Roof Works (Roof Parts, Clearlite, Gutter and AC Mounts Replacement, and Remediation) – Main Building Contractor (the Contract Works).

Main Contractor for the Blocks A, E, M4, Q1, XC, XB, D: Internal Upgrades - Carpet & Wall Coverings at Rosehill College

Ministry of Education - School Infrastructure — Sun, 18 Oct 2026 20:00:00 GMT

RFx ID:	35225827
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 9:00 AM +13:00
Close date:	Tuesday, 17 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for Rosehill College (the School) – Blocks A, E, M4, Q1, XC, XB, D: Internal Upgrades - Carpet & Wall Coverings – Main Building Contractor (the Contract Works).

Main Contractor for the Blocks A, B, C, D, E, F, G, Q1, XB, XC, C2, F1, YB, MB, J: Plumbing Items Replacement: Taps / Toilets/ Hot Water Cylinders / Showers at Rosehill College

Ministry of Education - School Infrastructure — Sun, 18 Oct 2026 20:00:00 GMT

RFx ID:	35225522
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 9:00 AM +13:00
Close date:	Tuesday, 17 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for Rosehill College (the School) – Blocks A, B, C, D, E, F, G, Q1, XB, XC, C2, F1, YB, MB, J: Plumbing Items Replacement: Taps / Toilets/ Hot Water Cylinders / Showers – Main Building Contractor (the Contract Works).

Main Contractor for the Blocks A, D, E G, Q1, F, S, YB, MA, P, R1: Lifecycle Replacement of Roof, Roof Parts, Clearlite, Gutters (Incl. ACM Gutter) at Rosehill College

Ministry of Education - School Infrastructure — Sun, 18 Oct 2026 20:00:00 GMT

RFx ID:	35225350
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 9:00 AM +13:00
Close date:	Tuesday, 17 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for Rosehill College (the School) – Blocks A, D, E G, Q1, F, S, YB, MA, P, R1: Lifecycle Replacement of Roof, Roof Parts, Clearlite, Gutters (Incl. ACM Gutter) – Main Building Contractor (the Contract Works).

Main Contractor for the Block 4: Food Technology Repurposing at Rosehill Intermediate School

Ministry of Education - School Infrastructure — Sun, 18 Oct 2026 20:00:00 GMT

RFx ID:	35224518
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 9:00 AM +13:00
Close date:	Tuesday, 17 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for Rosehill Intermediate School (the School) – Block 4: Food Technology Repurposing – Main Building Contractor (the Contract Works).

Main Contractor for the Blocks 1, 2, 3, 4, 5, 7, 10, 11, Site: Roof Works - Roof , Gutter & Internal Gutter + Roof Parts & AC Mount at Rosehill Intermediate School

Ministry of Education - School Infrastructure — Sun, 18 Oct 2026 20:00:00 GMT

RFx ID:	35224190
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 9:00 AM +13:00
Close date:	Tuesday, 17 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	This Request for Tenders (RFT) open invitation to Contractors (Tenderers) to submit a Tender for Rosehill Intermediate School (the School) – Blocks 1, 2, 3, 4, 5, 7, 10, 11, Site: Roof Works – Roof, Gutter & Internal Gutter + Roof Parts & AC Mount Replacement – Main Building Contractor (the Contract Works).

Main Building Contractor for Blk A B Toilets Heating Electrical Upgrades & Classroom Remediation at Taradale High School

Ministry of Education - School Infrastructure — Thu, 15 Oct 2026 20:00:00 GMT

RFx ID:	35221326
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 16 October 2026 9:00 AM +13:00
Close date:	Tuesday, 17 November 2026 5:00 PM +13:00
Categories:	72121100 - Commercial and office building construction services
Region:	Hawke's Bay
Overview:	To seek expressions of interest from qualified contractors to undertake comprehensive facility upgrades to the Classrooms and Ablution areas in Blocks A and B. The project includes electrical upgrades, heat pump installations, ceiling repairs/replacements, wall finishes, and full plumbing replacements. Submissions will be formally assessed to determine a shortlist of suitable candidates who will be invited to tender.

Main-Contractor Builder : 5YA : Block 1 - 5YA Roofing Replacement Project for Greenmeadows Int. School, Sth Auckland.

Ministry of Education - School Infrastructure — Wed, 21 Oct 2026 20:00:00 GMT

RFx ID:	35263430
Organisation:	Ministry of Education - School Infrastructure
Open date:	Thursday, 22 October 2026 9:00 AM +13:00
Close date:	Tuesday, 17 November 2026 4:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	Registrations of Interest are sort for Builder Main-Contractors to price the supply and installation works of a 5YA Block 1 Roofing Replacement project at Greenmeadows Intermediate School, Auckland. The existing roofing have reached the end of their lifecycle and become old and require replacement with the administration block experiencing multiple aeras of leaking. This project will require site visits and the appropriate inspections to determine the supply and installation of the required materials. All documentation will be prepared by the PM consultant, to NZ Safety Codes and MoE standards. All procedures to comply with MoE property legislation.

Tararua College Technology Block Window Replacement

Ministry of Education - School Infrastructure — Mon, 19 Oct 2026 20:30:00 GMT

RFx ID:	35238985
Organisation:	Ministry of Education - School Infrastructure
Open date:	Tuesday, 20 October 2026 9:30 AM +13:00
Close date:	Tuesday, 17 November 2026 4:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Hawke's Bay Manawatu-Wanganui
Overview:	This project is to remove Shugg window units and install new fixed and awning windows in existing frames and remediate internal localised areas.

Main contractor or Roofer for roof repairs, roof replacement, minor window joinery and cladding replacement at Rotorua Boys High School

Ministry of Education - School Infrastructure — Mon, 19 Oct 2026 20:30:00 GMT

RFx ID:	35221458
Organisation:	Ministry of Education - School Infrastructure
Open date:	Tuesday, 20 October 2026 9:30 AM +13:00
Close date:	Tuesday, 17 November 2026 4:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Bay of Plenty
Overview:	Site overview attached at document 6. Document 7; site specific plans to be loaded as NTT week starting 19/10/2026 i. Roof of Block A – Undertake ridge resealing, skylight and chimney flashing replacement, full roof re-screwing, fixing remediation and associated roof maintenance works to improve weather-tightness and roof performance. ii. Roof of Block B – Undertake replacement of rusted roof fixings and deteriorated downpipes, resealing of ridge and flashing joins, and associated roof maintenance works to restore weather-tightness. iii. Roof of Block C – Replace rusted roof fixings and supply and install the missing barge flashing to improve weather-tightness and roof performance. iv. Roof, cladding and joinery of Block G – Undertake roof, cladding, window joinery, drainage and safety remediation works as identified in the MoE Construction Advisor’s report. v. Roof of Block N – Undertake apron flashing resealing and replacement/remediation of the deteriorated fascia to restore weather-tightness and maintain building fabric integrity. vi. Roof of Block S – Undertake replacement of failed roofing, insulation, gutters, flashings and fixings, including full replacement of the internal membrane gutter and associated remediation works. vii. Roof of Block T – Undertake replacement of the deteriorated roof areas, flashings, insulation, gutters and spouting, together with resealing and repair of the internal membrane gutter, with no works required to the roof section currently in good condition. viii. Roof of Block X4 – Undertake full roof replacement, including substrate repairs, insulation, flashings, gutters and spouting, reinstatement of affected internal linings, and relocation of rooftop A/C inverter units where practicable.

Blocks A & C Floorcoverings Replacement at Feilding High School

Ministry of Education - School Infrastructure — Thu, 15 Oct 2026 20:00:00 GMT

RFx ID:	35189947
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 16 October 2026 9:00 AM +13:00
Close date:	Tuesday, 17 November 2026 4:00 PM +13:00
Categories:	72152500 - Floor laying services 72153600 - Interior finishing and furnishing and remodeling services
Region:	Manawatu-Wanganui
Overview:	The School require the removal of existing floorcoverings and their replacement with new carpet tiles, all-weather carpet to classroom corridors and vinyl sheet flooring to selected rooms. Block C is a single storey 14 classroom block and Block A is main the administration office area for the school. The final extent of the scope of works may be adjusted to suit the Schools available budget. It is anticipated that making use of School holidays will be required, work will continue during the School term with access being limited to 2 classrooms at one time in Block C and up to 3 offices at one time in Block A. handover over each stage will be required prior to being given access to the following stage.

RFT for Main Flooring Contractor for Blocks A & B Floor and Wall Coverings at Whangarei Girls High School

Ministry of Education - School Infrastructure — Sun, 18 Oct 2026 20:00:00 GMT

RFx ID:	35235314
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 9:00 AM +13:00
Close date:	Monday, 16 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Northland
Overview:	i. This project will undertake lifecycle replacement of floor and wall coverings throughout Block A and B.

Main Building Contractor for H O Student Toilets Refurbisment at Tahatai Coast School

Ministry of Education - School Infrastructure — Sun, 18 Oct 2026 20:00:00 GMT

RFx ID:	35232746
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 9:00 AM +13:00
Close date:	Monday, 16 November 2026 5:00 PM +13:00
Categories:	72121100 - Commercial and office building construction services
Region:	Bay of Plenty
Overview:	To seek a main building contractor to carry out the refurbishment of the students toilets in Blocks H & O in poor condition. Including flooring, hardware and sanitary ware replacement, supply and provision of ventiallation, new partitions, lighting upgrade, hot water installation and wet linings installation.

Main Contractor for P: Pavilion Changing Rooms Refurbishment at Kelston Boys High School

Ministry of Education - School Infrastructure — Sun, 18 Oct 2026 20:00:00 GMT

RFx ID:	35229167
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 9:00 AM +13:00
Close date:	Monday, 16 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	Main Contractor for P: Pavilion Changing Rooms Refurbishment at Kelston Boys High School

RFT for Main Contractor for Drainage Works at Parua Bay School

Ministry of Education - School Infrastructure — Sun, 18 Oct 2026 20:00:00 GMT

RFx ID:	35210358
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 9:00 AM +13:00
Close date:	Monday, 16 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Northland
Overview:	The school is situated on the side of a hill and suffers from substantial water run-off through the carparks to the school and playcentre. CCTV investigations found the existing underground stormwater system and outlet from the school is too small and it regularly gets inundated. The gravel carpark to the playcentre has no existing drainage and it is continually being eroded by the water coming off the road reserve and school carpark above. The playcentre requires drainage and a concrete surface to prevent this from happening. The additional water capture will add more capacity to what an undersized stormwater network is already. Therefore, this must be upgraded at the same time as the playcentre carpark works.

TKKM Rāwhiti Roa – Site: Drainage Works – Main Construction Contractor

Ministry of Education - School Infrastructure — Sun, 18 Oct 2026 20:00:00 GMT

RFx ID:	35047163
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 9:00 AM +13:00
Close date:	Monday, 16 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Northland
Overview:	The outcome sought from this procurement is the securing of the services of a suitably qualified and experienced main contractor to undertake the proposed Site: drainage works. The Kura’s original 5YA project scope included a drainage works design project. The system has had urgent remediation works undertaken already and the design of the new drainage system is complete. Due to the location of the proposed works and potential for disruption of the Kura’s operations, the contract works must be delivered during school holidays. The proposed scope includes the replacement of existing concrete paving to direct surface water towards new overland flow paths between Blocks 2, 3 & 5. The existing covered way path currently acts like a dam preventing surface water to flow through the natural flow path, so grated channels are proposed to allow water to escape when the surface flow exceeds the capacity of the existing catchpit. Additional ground contouring is proposed to deflect surface water from the area and instead direct to an existing adjacent catchpit and drainage network. Additionally, there are several areas of replacement drainage works required following a recent CCTV of the existing drains at the Kura. There is also some remedial wastewater drainage required, including the installation of new access chambers to resolve a sharp bend in the existing WW drainage infrastructure that has a tendency to block regularly.

MRGS Roofing Works – MCL Centre, Swimming Pool Changing Rooms, Uniform Shop and Blocks 3, 4 and 8 – Roof Replacement and Roof Remedial Works

Ministry of Education - School Infrastructure — Sun, 18 Oct 2026 20:00:00 GMT

RFx ID:	35228813
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 9:00 AM +13:00
Close date:	Monday, 16 November 2026 4:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	MRGS Roofing Works – MCL Centre, Swimming Pool Changing Rooms, Uniform Shop and Blocks 3, 4 and 8 – Roof Replacement and Roof Remedial Works

Main Contractor for Mangamuka School Block 1,5,A,B,D,E Upgrades

Ministry of Education - School Infrastructure — Wed, 14 Oct 2026 22:30:00 GMT

RFx ID:	35205113
Organisation:	Ministry of Education - School Infrastructure
Open date:	Thursday, 15 October 2026 11:30 AM +13:00
Close date:	Monday, 16 November 2026 4:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Northland
Overview:	The project comprises a coordinated programme of property improvement works at Mangamuka School - Scope of Works, including replacement of existing storage sheds, refurbishment of the pool changing facilities, pool infrastructure upgrades, development of a new playground and bike track, site improvements, signage upgrades, and associated minor refurbishment works. The works will be delivered under a single Main Contract to improve efficiency, coordination, and value for money

Safer Drinking Water in Schools (SDWS) Programme - Horowhenua District Bundle - RFQ

Ministry of Education - School Infrastructure — Wed, 21 Oct 2026 02:00:00 GMT

RFx ID:	35282991
Organisation:	Ministry of Education - School Infrastructure
Open date:	Wednesday, 21 October 2026 3:00 PM +13:00
Close date:	Friday, 13 November 2026 5:00 PM +13:00
Categories:	72151100 - Plumbing construction services
Region:	Manawatu-Wanganui
Overview:	The Ministry of Education is seeking tenders for the delivery of drinking water infrastructure upgrades at Manakau School and Opiki School in the Horowhenua District as part of the Drinking Safer Water in Schools (DSWS) Programme. The programme has been established to address drinking water compliance requirements under the Water Services Act 2021 and improve the safety, reliability and resilience of self-supplying school water systems. Both schools have undergone condition assessments and design development, which have identified infrastructure upgrades required to improve drinking water quality, storage capacity, system resilience, and compliance with Ministry standards. Works vary by school but generally include new drinking water storage tanks, treatment sheds, telemetry and smart metering systems, first flush diverters, treatment equipment upgrades, associated pipework, electrical works, civil works, and commissioning activities. At Manakau School, the works will consolidate the school's existing separate rainwater collection and storage systems into a single compliant rainwater supply network, while at Opiki School, the works will replace ageing storage infrastructure and address deficiencies within the existing water collection and distribution systems. The Ministry has bundled the two schools into a single procurement package to improve delivery efficiency and streamline contractor mobilisation across the region. The successful contractor will be required to work within live school environments, minimise disruption to school operations, maintain strong health and safety practices, and coordinate closely with school stakeholders throughout delivery. Tender evaluation will be based on price (50%), proposed solution (20%), capability (10%), capacity (10%), and economic benefits (10%). Works are expected to commence in December 2026, with completion targeted by March 2027

Main Contractor - Tari / Admin alterations at Te Wharekura o Rakaumanga

Ministry of Education - School Infrastructure — Mon, 19 Oct 2026 22:00:00 GMT

RFx ID:	35255230
Organisation:	Ministry of Education - School Infrastructure
Open date:	Tuesday, 20 October 2026 11:00 AM +13:00
Close date:	Friday, 13 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Waikato
Overview:	Te Wharekura o Rakaumanga Board of Trustees is seeking a main building contractor for the extension and refurbishment of the administration building.

Ngata Memorial College - Pool Filtration Replacement

Ministry of Education - School Infrastructure — Fri, 16 Oct 2026 02:00:00 GMT

RFx ID:	35233537
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 16 October 2026 3:00 PM +13:00
Close date:	Friday, 13 November 2026 5:00 PM +13:00
Categories:	49241700 - Swimming pool and spa equipment and supplies 72000000 - Building and Facility Construction and Maintenance Services
Region:	Gisborne
Overview:	The Buyer is seeking a suitably experienced pool contractor to undertake replacement of the existing swimming pool filtration and pump system at Ngata Memorial College, Ruatōria, together with associated remediation works within Block Q. The existing pool filtration system, pump and associated pipework are corroded and at the end of their serviceable life. The works generally comprise replacement of the pool filtration and pump system, installation of a chlorine automatic dosing system, replacement and modification of associated pipework within the pool plant area, and repair of the identified leaking filtration pipework within Block Q. The works will be undertaken in accordance with the technical design, drawings, specification and/or report being prepared by Amotto. This technical documentation is currently being finalised and will be issued to all Respondents by Notice to Tenderers through GETS during the RFQ period, anticipated during the week commencing 19 October 2026. Once issued, the Amotto technical documentation will form part of the RFQ documentation and the Requirements. The Successful Respondent will be responsible for providing all labour, materials, equipment, plant, supervision, electrical and controls work, installation, testing, commissioning, training and completion documentation necessary to provide a complete and operational pool filtration system.

Ngata Memorial College - Plumbing & Drainage Remediation Works

Ministry of Education - School Infrastructure — Fri, 16 Oct 2026 02:30:00 GMT

RFx ID:	35233158
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 16 October 2026 3:30 PM +13:00
Close date:	Friday, 13 November 2026 5:00 PM +13:00
Categories:	72101500 - Building maintenance and repair services
Region:	Gisborne
Overview:	The Buyer is seeking a suitably experienced plumbing and drainage contractor to undertake plumbing and drainage remediation works across Blocks A1, B, C1, D, J and Q at Ngata Memorial College, Ruatōria. The works comprise a series of identified remediation items including septic system repairs, gulley trap lids, downpipe leaf diverters, investigation and repair of a blocked/broken drain, and repair of leaking filtration pipework. The Successful Respondent will be responsible for confirming site conditions and the extent of the required works and for providing all labour, materials, plant, excavation, disposal, reinstatement, testing, supervision and completion documentation necessary to complete the works.

Hillcrest High School Design and build contractor for new sports canopy type building RoI

Ministry of Education - School Infrastructure — Sun, 18 Oct 2026 20:00:00 GMT

RFx ID:	35232938
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 9:00 AM +13:00
Close date:	Friday, 13 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Waikato
Overview:	This opportunity is for a design and build contractor with experience and capability to undertake the design and build of a proposed new sports canopy. The canopy is not proposed as being a tensioned PVC type barrel rolled structure commonly referred to as a COLA but rather is a anticipated to be of more rigid construction but also not a 'building' like a gymnasium. The canopy will not be full weatherproof however is expected to allow for all year round undercover use for various sports.

Main Contractor for Blocks 1, 2, 7, 8, 11, 12, C: Roofing Works at Owairaka District School

Ministry of Education - School Infrastructure — Thu, 15 Oct 2026 20:00:00 GMT

RFx ID:	35217807
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 16 October 2026 9:00 AM +13:00
Close date:	Friday, 13 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	The project aims to address identified roofing defects and deterioration across Blocks 1, 2, 7, 8, 11, 12, C to restore and maintain weathertightness, improve roof safety and durability, and ensure compliance with Ministry of Education (MoE) requirements. The works will provide a safe, fit-for-purpose roofing system while minimising disruption to school operations

Main Contractor for Blocks 1, 2, 7, 7A, 8, 11, 17, P: Roofing Works at Papatoetoe West School

Ministry of Education - School Infrastructure — Thu, 15 Oct 2026 20:00:00 GMT

RFx ID:	35217077
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 16 October 2026 9:00 AM +13:00
Close date:	Friday, 13 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	The roofing works have been identified as necessary due to deteriorated roof cladding, gutters, downpipes, flashings, Clearlite and roof penetrations across multiple school buildings. Leaks and areas of poor condition require remedial works to prevent further water ingress, protect the building fabric and maintain the long-term performance of the school property.

RFT - Ohope Beach School - 5YA Internal Refurbishment and Storage Improvements Blocks: A & B

Ministry of Education - School Infrastructure — Thu, 15 Oct 2026 20:00:00 GMT

RFx ID:	35206319
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 16 October 2026 9:00 AM +13:00
Close date:	Friday, 13 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Bay of Plenty
Overview:	The Board of Trustees of Ohope Beach School invites tenders from suitably qualified contractors for Internal Refurbishment and Storage Improvements for Blocks A & B under the Ministry of Education 5YA programme. The works will be delivered under a Medium Works Contract. The successful contractor will be responsible for all associated demolition, removals, making good, testing, commissioning, certification, cleaning and handover requirements. The project includes asbestos removal works, which must be undertaken by appropriately qualified and accredited personnel. Physical works are scheduled to commence on 18 December 2026 and must be completed by 29 January 2027. Tenderers will be evaluated on methodology, capability, capacity, economic benefits and price. Contractors with relevant experience delivering remediation and renewal works in operational school environments are encouraged to submit a tender.

RFT Main Building Contractor HO Refurbishment at Matamata College

Ministry of Education - School Infrastructure — Thu, 15 Oct 2026 00:30:00 GMT

RFx ID:	35202775
Organisation:	Ministry of Education - School Infrastructure
Open date:	Thursday, 15 October 2026 1:30 PM +13:00
Close date:	Friday, 13 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Waikato
Overview:	This Request for Tenders (RFT) is an open invitation to Contractors to submit a Tender for Matamata College HO Block Refurbishment Project – Main Contractor

TKKM o Te Ara Hou Cyclical Maintenance External Painting Project

Ministry of Education - School Infrastructure — Mon, 12 Oct 2026 23:30:00 GMT

RFx ID:	35164340
Organisation:	Ministry of Education - School Infrastructure
Open date:	Tuesday, 13 October 2026 12:30 PM +13:00
Close date:	Friday, 13 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Hawke's Bay
Overview:	Blocks A, B, C, D, E, F, G, H, I, J, M, N, U, toilet building and Waharoa - preparation for and painting of all paintable external surfaces throughout the Kura

Main Building Contractor for Matauri Bay School - Blocks 1, 5 & 6 Refurbishment

Ministry of Education - School Infrastructure — Thu, 01 Oct 2026 20:00:00 GMT

RFx ID:	35059140
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 2 October 2026 9:00 AM +13:00
Close date:	Friday, 13 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland Northland
Overview:	Matauri Bay School is a rural Year 1-8 school located at 2223-2231 Whakarara Road, Matauri Bay, Northland. The project comprises refurbishment and alteration works to Blocks 1, 5 and 6 to address identified lifecycle, weathertightness, accessibility, fire safety and building envelope deficiencies. The works include roof replacement, cladding replacement, asbestos remediation, replacement joinery, ceiling replacement, insulation upgrades, flooring replacement, administration reconfiguration and accessibility improvements Refurbished and modernised teaching, administration and support spaces within Blocks 1, 5 and 6 that are safe, compliant, weather-tight and fit for purpose. • Renewal of ageing building elements including roofing, external cladding, windows, doors, ceilings, flooring and insulation to extend asset life and reduce future maintenance requirements. • Improved building performance through upgraded thermal envelope components, replacement joinery, ceiling systems and insulation in accordance with current Ministry of Education standards. • Improved accessibility through the construction of a new compliant entrance, decking and accessible ramp. • Enhanced administration facilities including alterations to administration spaces, Principal's office, sickbay and storage area. • Safe Removal and replacement of asbestos-containing building elements. • A staged construction programme that allows the school to remain operational throughout the works while maintaining safety for students, staff and visitors.

Main Building Contractor for Te Kura o Omanaia - Block 3, 11, 1 A Replacements

Ministry of Education - School Infrastructure — Mon, 28 Sep 2026 20:00:00 GMT

RFx ID:	35033495
Organisation:	Ministry of Education - School Infrastructure
Open date:	Tuesday, 29 September 2026 9:00 AM +13:00
Close date:	Friday, 13 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:
Overview:	Te Kura o Ōmanaia is seeking a suitably experienced Main Contractor to deliver a bundled programme of refurbishment, lifecycle replacement and site improvement works at the School. The Contract Works combine several workstreams into a single construction package to achieve efficient delivery, coordinated site management and value for money. The works generally comprise: Block 3: Removal of existing unsuitable wall coverings within the cooking room and installation of new durable, hygienic wall linings suitable for food preparation activities. Block 11: Removal and replacement of deteriorated timber decking, landing and steps, including inspection and remediation of underlying supporting structures where required. Block A / Pool Changing Facilities: Refurbishment of the existing pool changing facility, including decking, flooring, internal linings, sanitary fixtures, plumbing, partitions and external doors. Swimming Pool: Pool preparation and fibreglass relining, together with replacement and upgrade of associated skimmers, pipework, pump, filtration equipment and ancillary infrastructure. The successful Main Contractor will be responsible for overall site establishment, programming, supervision, health and safety, management of subcontractors and nominated specialists, protection of existing facilities, quality assurance, commissioning and handover. The School is expected to remain operational during portions of the works. Tenderers must demonstrate suitable experience and capability in delivering refurbishment works within operational school or similarly occupied environments. The preferred construction commencement is 18 December 2026, with works programmed to maximise the summer school holiday period and minimise disruption to teaching and learning.

Paengaroa School - Building works

Ministry of Education - School Infrastructure — Fri, 18 Sep 2026 04:30:00 GMT

RFx ID:	34972410
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 18 September 2026 4:30 PM +12:00
Close date:	Friday, 13 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Bay of Plenty
Overview:	Various maintenance work on various blocks at Paengaroa School, Paengaroa, BOP Additional scope clarification and specification added 4/11/2026

RFT - Main Roofing Contractor for Roofing Project at Chapel Downs School

Ministry of Education - School Infrastructure — Tue, 13 Oct 2026 20:00:00 GMT

RFx ID:	34970360
Organisation:	Ministry of Education - School Infrastructure
Open date:	Wednesday, 14 October 2026 9:00 AM +13:00
Close date:	Friday, 13 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	School Roofing Project located in Flat Bush Auckland Construction between 5th Jan 2027 and 29th Jan 2027 This procurement aims to replace identified portions of the school roofing derived from a recent Condition Assessment and BOT/Ministry agreed 5YA plan, multiple partial roof areas were identified as being in need of replacement and therefore requiring removal & disposal of existing roofing material. Other areas of gutter replacement also required.

Stratford Primary School Main Contract Works – Relocation of Wharenui & Demolition Block F RFT

Ministry of Education - School Infrastructure — Sun, 18 Oct 2026 20:00:00 GMT

RFx ID:	35237620
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 19 October 2026 9:00 AM +13:00
Close date:	Thursday, 12 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Taranaki
Overview:	Block F at Stratford Primary School was identified with weathertightness issues in 2016 and originally scoped for remediation under the Taranaki Cluster but the work had to be paused due to insufficient funding being available. The remediation of Block F was revisited in 2023, with a preliminary design completed in May of that year. The extensive nature of the required remediation due to the modulock construction and the lack of cost advantages meant the scope was revised with classroom replacement being recommended instead. The new scope agreed in 2025 includes: o Demolition of 3TS and Wharenui (1TS) in Block F o Refurbish, relocate, and convert Classroom 20 (K2 reference Classroom 1) into new Wharenui (1TS) o General siteworks, infrastructure, and sandpit relocation

RFT for Main Contractor for New Carpark Project at Moerewa School

Ministry of Education - School Infrastructure — Mon, 12 Oct 2026 20:00:00 GMT

RFx ID:	35177150
Organisation:	Ministry of Education - School Infrastructure
Open date:	Tuesday, 13 October 2026 9:00 AM +13:00
Close date:	Thursday, 12 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Northland
Overview:	The project will provide additional parking for staff, whānau, and visitors, addressing the school's current shortage of available parking spaces. Stage 2 of the project includes the completion of associated fencing and landscaping works to support the new car park and enhance the overall functionality and appearance of the area.

RFT - Demolition Contractor for Block D - Rationalisation at Pukeatua Primary School, Wainuiomata, Lower Hutt

Ministry of Education - School Infrastructure — Mon, 05 Oct 2026 20:00:00 GMT

RFx ID:	35084757
Organisation:	Ministry of Education - School Infrastructure
Open date:	Tuesday, 6 October 2026 9:00 AM +13:00
Close date:	Thursday, 12 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Manawatu-Wanganui Wellington
Overview:	Block D at Pukeatua Primary School is in poor condition, is beyond economical investment and surplus to requirements. The School Property Agency has approved rationalisation funding, and it has been agreed to demolish the block, disconnect and cap off services and reinstate the grounds.

Main contractor for Hall gutter and roof work, and floor remediation at Mihi School

Ministry of Education - School Infrastructure — Thu, 15 Oct 2026 02:00:00 GMT

RFx ID:	35216632
Organisation:	Ministry of Education - School Infrastructure
Open date:	Thursday, 15 October 2026 3:00 PM +13:00
Close date:	Thursday, 12 November 2026 4:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Bay of Plenty
Overview:	a. Based on Condition-Assessment-Mihi-School-Andrew-Golding-11-Apr-2025, the project is focused on investigating and addressing water ingress issues affecting the Mihi School Hall building. The assessment identified several high-risk areas, including roof-to-wall junctions, flashing details, gutters, glazing interfaces, and door openings that may be allowing water penetration into the building. This may include: i. The assessment recommends remedial works to improve the weathertightness performance of the building and reduce the risk of future water intrusion. ii. Has experienced ongoing water ingress issues within the Hall building. A condition assessment identified potential defects associated with roof and wall junctions, flashing arrangements, gutter design, glazing interfaces, and external door details. Evidence of moisture damage was observed internally, including deterioration to flooring finishes. a. The Contract Works required are: i. Investigate and rectify water ingress pathways affecting the Hall building. ii. Repair or redesign deficient roof, flashing, and gutter interfaces. iii. Improve weatherproofing around glazing systems and external doors. iv. Removal of existing areas of damaged flooring around entrances, install fixed heavy duty inlaid entrance matting, size to be confirmed on site.

Main contractor for Library Cladding Replacement at Tongariro School

Ministry of Education - School Infrastructure — Wed, 14 Oct 2026 22:30:00 GMT

RFx ID:	35188729
Organisation:	Ministry of Education - School Infrastructure
Open date:	Thursday, 15 October 2026 11:30 AM +13:00
Close date:	Thursday, 12 November 2026 4:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Bay of Plenty
Overview:	2.1 Background a. Based on the condition assessment completed by Andrew Golding dated 8 August 2024, the project is focused on improving the weathertightness performance of the Library building through remediation of the external building envelope. i. The works include replacement of existing wall cladding systems, installation of new cavity-based cladding and associated flashings. ii. Replacement of soffit linings, and reinstatement of affected rainwater goods and external building elements. iii. These works are intended to address identified weathertightness deficiencies and improve the long-term durability and performance of the building. iv. The recommended works are intended to improve the overall weathertightness performance of the building, address identified defects, reduce the risk of ongoing water intrusion, and protect the long-term integrity of the building structure. 2.2 Required Solution i. Removal of the existing wall cladding to the framed external walls of the Library and installation of new cavity-based Linea weatherboard and Axon panel cladding systems, including new wall underlay, cavity battens, flashings, seals, fixings and associated weatherproofing components. ii. Removal of asbestos-contaminated cladding panels and soffit linings in accordance with the applicable asbestos health and safety requirements, including off-site disposal at an approved facility. iii. Installation of new soffit linings over the existing framing, with the existing framing made good as required to receive the new work. iv. Existing windows, roofing, roof structure, masonry walls, internal layouts, finishes and building systems are to remain, unless specifically affected by or identified for alteration as part of the documented works. v. The school will remain operational throughout construction. The Contractor will be required to securely isolate the work area with temporary fencing and maintain existing services and compliance schedule systems, and coordinate deliveries so they do not occur during class or break times. vi. Known site constraints include working within an operational school, managing asbestos-containing materials, maintaining safe access and egress, protecting existing services and building elements, and verifying existing site dimensions, framing and conditions before commencing work.

RFT Rototuna High School B Gym Wall Lining

Ministry of Education - School Infrastructure — Wed, 14 Oct 2026 21:00:00 GMT

RFx ID:	35184882
Organisation:	Ministry of Education - School Infrastructure
Open date:	Thursday, 15 October 2026 10:00 AM +13:00
Close date:	Thursday, 12 November 2026 3:00 PM +13:00
Categories:	72151400 - Wall covering construction services
Region:	Waikato
Overview:	The current wall system is structurally inadequate and poses safety risks due to the poor original installation. The proposed works will ensure long-term durability, compliance with safety and fire standards, and improved safety for gym users requirements for phasing and / or staged handover of the project will be required as the gym is a live environment with usage booked in advance, coordination with The Peak management will be required Fosters Maintain and Thorburn Builders have been previously engaged to carry out repairs and invasive investigation works to confirm extent of works required. General Scope; Remove existing lower section of plywood panels, and dispose Carry out necessary remedial works to the substructure and rondo system to allow for installation of new plywood panels, which may include removal of inadequate framing, battens and fixings in affected areas and Install new support framing to provide a rigid fixing substrate for the wall lining and existing curtain winch brackets and other existing wall fixings Install new wall linings. Make good and recoat affected areas to match existing finishes. Where necessary remove curtain system and reinstate on completion. Reinstate and test curtain operation to original/current working order and ensure all fixings and brackets altered during replacement works are secure upon completion Remove all waste materials and leave the area clean and operational on completion of each staged works. Floor protection will be required for the work area as new coating is to be applied. Works will not be able to be carried out during this period of December 21st through to January 5th.

(1917) Te Wharekura o Rākaumangamanga #262010 Block P: Gym Refurbishment

Ministry of Education - School Infrastructure — Mon, 12 Oct 2026 21:00:00 GMT

RFx ID:	35147393
Organisation:	Ministry of Education - School Infrastructure
Open date:	Tuesday, 13 October 2026 10:00 AM +13:00
Close date:	Wednesday, 11 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Waikato
Overview:

Main Contractor ROI Design & Build Ablutions Block at Macleans College

Ministry of Education - School Infrastructure — Mon, 19 Oct 2026 20:00:00 GMT

RFx ID:	35256284
Organisation:	Ministry of Education - School Infrastructure
Open date:	Tuesday, 20 October 2026 9:00 AM +13:00
Close date:	Tuesday, 10 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:

Plumbing & Drainage Contractor for plumbing upgrades at Makoura College

Ministry of Education - School Infrastructure — Sun, 11 Oct 2026 21:00:00 GMT

RFx ID:	35150926
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 12 October 2026 10:00 AM +13:00
Close date:	Tuesday, 10 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Manawatu-Wanganui Wellington
Overview:	The Makoura College Board of Trustees seek the services of a Plumbing & Drainage Contractor to undertake drainage and water services upgrades across multiple school blocks. The works include replacement and repair of gully traps and roof water drainage components, replacement of drinking fountains, hot water systems and water boilers, adjustment of tempered water settings, associated pipework and fittings, testing and commissioning, excavation and reinstatement works, and all required building make-good works.

Dargaville High School – Shade Structure Installation

Ministry of Education - School Infrastructure — Mon, 12 Oct 2026 20:00:00 GMT

RFx ID:	35135703
Organisation:	Ministry of Education - School Infrastructure
Open date:	Tuesday, 13 October 2026 9:00 AM +13:00
Close date:	Tuesday, 10 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Northland
Overview:	The work required is the turn-key design and build of a standalone, open-ended tensile membrane canopy over the existing asphalt multi-sport courts at Dargaville High School. The Contract Works include: - Structural engineering, 3D modelling, and working and shop drawings - Building consent, including all documentation and producer statements (PS1, PS3 and PS4) needed for the Code Compliance Certificate - A NZ-fabricated, hot-dip galvanised steel frame with a minimum 50-year design life, compliant with the NZ Building Code, AS/NZS 5131 and AC1828 - A PVC tensile membrane (SKY W9400 or equivalent) with a maximum of 13% light transmission, low glare and a minimum 25-year pro rata warranty - Bored pier foundations, independent of existing buildings. The indicative concept uses about 14 piers, each 900mm in diameter and 3.0 to 3.5m deep - Concrete and asphalt cutting, spoil disposal, and reinstating the court surface around each post - Rainwater collection connected to the existing stormwater system - Any geotechnical investigation needed, and locating underground services - As-built drawings, operation and maintenance manuals, and warranties at handover The works are on an operating school site. They will be delivered in a single stage with one handover at Practical Completion.

Main Building Contractor for Raurimu Avenue School - 1,5: Internal and External Refurbishments

Ministry of Education - School Infrastructure — Wed, 30 Sep 2026 20:00:00 GMT

RFx ID:	35057833
Organisation:	Ministry of Education - School Infrastructure
Open date:	Thursday, 1 October 2026 9:00 AM +13:00
Close date:	Tuesday, 10 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:
Overview:	Raurimu Avenue School is looking to complete a range of internal and external works within Block 1 as listed below • Block 1: Remove ACM and reclad Block 1 including replacement of the soffit. (Asbestos report to be done) • Block 1: Window and Shelter replacement • Block 1 & 5: Toilet Refurbishment and Vinyl Replacement in Cloak Bay All works must be completed to Ministry of Education standards, the New Zealand Building Code and relevant compliance requirements.

Main Contractor for Blocks1,3,4,6,8,12 Toilet Refurbishment at Oratia District School

Ministry of Education - School Infrastructure — Thu, 29 Oct 2026 20:00:00 GMT

RFx ID:	35344321
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 30 October 2026 9:00 AM +13:00
Close date:	Monday, 9 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	The Oratia District School Board is seeking a main contractor for Blocks 1,3,4,6,8,12 Toilet Refurbishment.

Electrical DBs, RCD and RCBO Protection works to various blocks Hillcrest High School

Ministry of Education - School Infrastructure — Sun, 11 Oct 2026 21:00:00 GMT

RFx ID:	35152108
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 12 October 2026 10:00 AM +13:00
Close date:	Monday, 9 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Waikato
Overview:	The project is more ideally suited to an experience Electrical Contracting Company with sufficient resources, qualified staff and capacity to undertake the systematic upgrading to multiple Electrical distribution boards across the school campus. Works is to upgrade multiple Electrical distribution boards by way of varying degrees of replacement DB's, installation of RCD/ RCBO as applicable.

Main Contractor forA, C, D, E, G, G2, H, L, O, P, 1, 2, 4, 5, 6: Roof, Clearlite, Gutter, Membrane Roof & Gutter + Roof Parts Replacements at Tangaroa College

Ministry of Education - School Infrastructure — Thu, 08 Oct 2026 20:00:00 GMT

RFx ID:	35147057
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 9 October 2026 9:00 AM +13:00
Close date:	Monday, 9 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:

Main Contractor for J M, H, W: Lifecycle Replacement of Floor and Wall Coverings at Tangaroa College

Ministry of Education - School Infrastructure — Thu, 08 Oct 2026 20:00:00 GMT

RFx ID:	35146777
Organisation:	Ministry of Education - School Infrastructure
Open date:	Friday, 9 October 2026 9:00 AM +13:00
Close date:	Monday, 9 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:

RFT - Main Building Contractor for the New Food Technology Room at Waiuku College

Ministry of Education - School Infrastructure — Sun, 11 Oct 2026 20:00:00 GMT

RFx ID:	35144402
Organisation:	Ministry of Education - School Infrastructure
Open date:	Monday, 12 October 2026 9:00 AM +13:00
Close date:	Monday, 9 November 2026 5:00 PM +13:00
Categories:	22000000 - Building and Construction Machinery and Accessories 72000000 - Building and Facility Construction and Maintenance Services 95000000 - Land and Buildings and Structures and Thoroughfares
Region:	Auckland
Overview:

Registration of Interest (ROI) for a Bathroom Refurbishment at Sunnybrae Normal School

Ministry of Education - School Infrastructure — Mon, 26 Oct 2026 20:30:00 GMT

RFx ID:	34821676
Organisation:	Ministry of Education - School Infrastructure
Open date:	Tuesday, 27 October 2026 9:30 AM +13:00
Close date:	Monday, 9 November 2026 5:00 PM +13:00
Categories:	72000000 - Building and Facility Construction and Maintenance Services
Region:	Auckland
Overview:	The School is planning to undertake these works. Refer to the ROI for detail on the scope of works. Site Visits are NOT permitted during this ROI stage.