Two Mile Creek Waihi Beach Erosion Protection Works

Details

Tender Closed
RFx ID :	25410229
Tender Name :	Two Mile Creek Waihi Beach Erosion Protection Works
Reference # :	21-1123
Open Date :	Tuesday, 1 March 2022 4:30 PM (Pacific/Auckland UTC+13:00)
Close Date  :	Friday, 25 March 2022 5:00 PM (Pacific/Auckland UTC+13:00)
Tender Type :	Request for Tenders (RFT)
Tender Coverage :	Sole Agency  [?]
Categories :	70171800 - Drainage services 72140000 - Heavy construction services 77110000 - Environmental protection 81101500 - Civil engineering
Regions:	Bay of Plenty
Exemption Reason :	None
Required Pre-qualifications :	None
Contact :	Laraine Jackett - Please raise questions via GETS procurement@westernbay.govt.nz
Alternate Physical Delivery Address  :
Alternate Physical Fax Number  :
Agency Address :	NEW ZEALAND

Western Bay of Plenty District Council (Western Bay) wishes to procure construction of approx. 300m of bank protection works at Two Mile Creek in Waihi Beach (upstream of Dillion St bridge). The works entail the supply of all material and the construction of the rock wall.

It is important for us that:
• the Respondent has experience in working in this type of environment.
• the Respondent has staff with the necessary skillset to successfully deliver this project.
• the Respondent has the ability and given due consideration to the interaction ensuring effective interaction with landowners
• the Respondent has robust supply chain management to ensure the supply for material.

The Contractor will be required to provide satisfactory proof that they (and their employees, representatives and or subcontractors) are fully vaccinated against COVID-19 before undertaking work on any Council premises or worksite.

Refer to Attachments for full details (including Response Form).

No Winner Tender unable to be awarded due to extensive consent delays and other changes affecting the project. Council decision to cease this tender and go to market again with a different approach.