Create New Account Purchaser Login
Search Tenders
Advanced Search
You are not logged in.

EOI for Pioneer RSC Earthquake Repair and R&R Cycle Shutdown


Tender Closed
RFx ID : 22961080
Tender Name : EOI for Pioneer RSC Earthquake Repair and R&R Cycle Shutdown
Reference # :
Open Date : Tuesday, 14 July 2020 2:00 PM (Pacific/Auckland UTC+12:00)
Close Date  : Monday, 3 August 2020 12:00 PM (Pacific/Auckland UTC+12:00)
Department/Business Unit : Infrastructure
Tender Type : Registration of Interest (ROI)
Tender Coverage : Sole Agency  [?]
Categories :
  • 22000000 - Building and Construction Machinery and Accessories
  • 30000000 - Structures and Building and Construction and Manufacturing Components and Supplies
  • 49000000 - Sports and Recreational Equipment and Supplies and Accessories
  • 72000000 - Building and Facility Construction and Maintenance Services
  • 95000000 - Land and Buildings and Structures and Thoroughfares
  • Canterbury
Required Pre-qualifications : None
Contact : Caio Lopes - Senior Procurement Specialist
Alternate Physical Delivery Address  :
Alternate Physical Fax Number  :
Agency Address :

Christchurch City Council (the Council) is seeking Expressions of Interest (EOI’s) from suitably qualified contractors (Respondents) who are interested in delivering earthquake repairs and installation of pool water services, mechanical and electrical installation at Pioneer Recreation and Sports Centre to the Council.

The purpose of this EOI is then to communicate to the market the Council’s needs to deliver the project, determine the market appetite to participate in a multistage procurement (EOI + RFT), understand Respondents expertise, capability and capacity to deliver the contracts works during the available timeframe (Mid-November 2020 throughout Mid-April 2021) at the Pioneer Recreation and Sports Centre shutdown.

The following high level steps are anticipated:
• An EOI to establish a group of Respondents
• An interactive EOI process to align expectations from both parties and discuss value for money initiatives
• A RFT to shortlisted Respondents
• Negotiation and due diligence stages may be undertaken with Respondents
• Presentation with Preferred Respondent if required
• Recommendations developed and approved
• Contract award

Awarded Status

This tender has been completed.

Completion date: Wednesday, 19 August 2020 11:13 AM (Pacific/Auckland UTC+12:00)