GETS Open Tenders or Quotes

27-023 Patterson Road Civil Construction Extension Project

New Plymouth District Council — Sun, 13 Sep 2026 20:30:00 GMT

RFx ID:	34921850
Organisation:	New Plymouth District Council
Open date:	Monday, 14 September 2026 8:30 AM +12:00
Close date:	Wednesday, 14 October 2026 12:00 PM +13:00
Categories:	22000000 - Building and Construction Machinery and Accessories 24000000 - Material Handling and Conditioning and Storage Machinery and their Accessories and Supplies 30000000 - Structures and Building and Construction and Manufacturing Components and Supplies 31000000 - Manufacturing Components and Supplies 72000000 - Building and Facility Construction and Maintenance Services 77000000 - Environmental Services 81000000 - Engineering and Research and Technology Based Services 83000000 - Public Utilities and Public Sector Related Services 91000000 - Personal and Domestic Services 95000000 - Land and Buildings and Structures and Thoroughfares
Region:	Taranaki
Overview:	This New Plymouth District Council tender will be accessible via Tenderlink, and is only being advertised via GETS. All further communications related to this tender will be conducted through TenderLink. New Plymouth District Council (NPDC) is seeking an experienced and suitably qualified civil construction contractor to deliver the Patterson Road Extension Phase 4B project, comprising the construction of stormwater infrastructure, a large in-stream box culvert, retaining wall structures, earthworks, and a new road extension. The successful contractor will provide end-to-end construction services to enable the delivery of critical growth infrastructure that supports future residential development within the Patterson Road Growth Area. A key feature of this project is the challenging topography, with sections of the new road reaching gradients of 17%. This project requires specialist expertise in pavement construction, earthworks management, drainage and temporary works that will incorporate safe construction practices. Our objectives are to: -Deliver the works safely while managing the risks associated with construction and the protection of the existing critical infrastructure and services. -Construct high-quality stormwater, culvert and roading assets that perform effectively in a challenging topographical environment. -Provide network resilience and long-term asset performance within the growth area. - Enable future residential development through the delivery of essential transport and stormwater infrastructure. -Minimise impacts on neighbouring properties and stakeholders through proactive planning and construction -Deliver the project within the approved budget and programme while maintaining exemplary standards of health, safety, environmental management and quality assurance.. To be able to participate in this tender and access the RFX documents, providers will need to ensure they are registered on TenderLink. The TenderLink portal is free to access and to upload submissions. We have published this advanced notice to alert potential respondents of the need to register in Tenderlink. Using the link below, please follow the instructions on the main screen of how to set up your organisation to access TenderLink (if you are not already registered). Please make sure your contact email address is accurate. https://www.tenderlink.com/npdc/

25/26-212 Te Pae o te Rangi Coastal Walkway Stage 2 (Waenga) & 3 (Runga)

New Plymouth District Council — Thu, 10 Sep 2026 03:00:00 GMT

RFx ID:	34911428
Organisation:	New Plymouth District Council
Open date:	Thursday, 10 September 2026 3:00 PM +12:00
Close date:	Monday, 12 October 2026 12:00 PM +13:00
Categories:	30000000 - Structures and Building and Construction and Manufacturing Components and Supplies 72120000 - Nonresidential building construction services 72140000 - Heavy construction services
Region:	Taranaki
Overview:	New Plymouth District Council tender will be accessible via Tenderlink, and is only being advertised via GETS. All further communications related to this tender will be conducted through TenderLink. To be able to participate in this tender and access the RFX documents, providers will need to ensure they are registered on TenderLink. The TenderLink portal is free to access and to upload submissions. New Plymouth District Council (NPDC) is seeking a contractor with proven expertise in delivering high-quality public walkways and coastal infrastructure projects in challenging environments. This will entail providing end-to-end construction, project management, and delivery services for Stages 2 (Waenga) & 3 (Runga) of the Te Pae o te Rangi This Coastal Walkway. These works are required to extend the existing coastal pathway and enhance public access, delivering a safe, durable, and visually integrated asset that reflects the natural and cultural values of the rohe. Stage 2 (Waenga) is defined as Tate Road to New Plymouth Airport and will include 3.8km of main path with a mix of concrete (1.6km a 2.6m wide & 0.7km a 1.8m wide) and asphalt (1.5km at 2.6m wide), rest areas, road crossing, furniture, balustrades and signage and 70m bridge over the Waiongana River. The Design for Stage 2 (Waenga) is completed, and an overview plan is attached as part of this EOI. The full design will be shared with the shortlisted tenderers during the RFP stage. Stage 3 (Runga) is defined as New Plymouth Airport to Tiromoana Cres and will include 2.6km a 2.6m wide of asphalt main path, rest areas, furniture, signage. The Bridge is planned to be executed as a design and construct package and contractors must be willing to work with the selected bridge contractor. The design and final route for stage 3 (Runga) is ongoing and minor adjustments to the above overview plan might occur. Planting and soft landscaping for both stages 2 (Waenga) & 3 (Runga) will be performed by hapū partners on the Te Pae o te Rangi project and contractors must be willing to work with the respective hapū partners. Using the link below, please follow the instructions on the main screen of how to set up your organisation to access TenderLink (if you are not already registered). Please make sure your contact email address is accurate. https://www.tenderlink.com/npdc/ If you require any further assistance, please contact procurementadmin@npdc.govt.nz

26-213 Rogan Street Signalisation

New Plymouth District Council — Wed, 09 Sep 2026 22:00:00 GMT

RFx ID:	34907225
Organisation:	New Plymouth District Council
Open date:	Thursday, 10 September 2026 10:00 AM +12:00
Close date:	Monday, 12 October 2026 12:00 PM +13:00
Categories:	22000000 - Building and Construction Machinery and Accessories 30000000 - Structures and Building and Construction and Manufacturing Components and Supplies 72140000 - Heavy construction services
Region:	Taranaki
Overview:	New Plymouth District Council tender will be accessible via Tenderlink, and is only being advertised via GETS. All further communications related to this tender will be conducted through TenderLink. To be able to participate in this tender and access the RFX documents, providers will need to ensure they are registered on TenderLink. The TenderLink portal is free to access and to upload submissions. NPDC is seeking suitably qualified and experienced contractors to deliver an intersection upgrade and associated civil works at the SH3 / Coronation Avenue intersection with Rogan Street. This project presents an opportunity to partner with NPDC on a well-defined urban transport improvement that prioritises safety, traffic efficiency, and access. The works will be carefully programmed to take advantage of the summer school holiday period, reducing impact on road users and nearby stakeholders while maintaining a strong focus on planning and execution excellence. We are looking for respondents who can demonstrate proven capability in delivering high-quality civil works to required standards, within constrained timeframes and budget. Successful respondents will bring robust project management, strong stakeholder coordination, and a commitment to delivering outcomes that meet NPDC standards for quality, programme, and cost certainty. This is a fit for contractors who excel in coordinated delivery under tight time windows and who can confidently manage both construction execution and community impact. The supplier must demonstrate how they will:  Safely and efficiently deliver all civil works to meet NPDC and NZTA quality standards  Effectively plan and schedule works to maximise productivity within the limited delivery window  Coordinate resources and subcontractors to support multiple work fronts if required  Implement proactive communication and stakeholder engagement strategies  Manage risks, including traffic management, safety, and programme constraints The contractor must be an NZTA (Waka Kotahi) approved contractor and must maintain all required accreditations and compliance standards necessary to undertake works on or within the State Highway network Using the link below, please follow the instructions on the main screen of how to set up your organisation to access TenderLink (if you are not already registered). Please make sure your contact email address is accurate. https://www.tenderlink.com/npdc/

Advanced Notice: Rogan Street Signalisation Project

New Plymouth District Council — Tue, 08 Sep 2026 03:00:00 GMT

RFx ID:	34888816
Organisation:	New Plymouth District Council
Open date:	Tuesday, 8 September 2026 3:00 PM +12:00
Close date:	Friday, 18 September 2026 12:00 PM +12:00
Categories:	32000000 - Electronic Components and Supplies 39000000 - Electrical Systems and Lighting and Components and Accessories and Supplies 72100000 - Building and facility maintenance and repair services 72120000 - Nonresidential building construction services 72140000 - Heavy construction services 72151500 - Electrical system services 72154300 - Motive and electrical power generation equipment maintenance and repair services 78180000 - Transportation repair or maintenance services 83100000 - Utilities 95000000 - Land and Buildings and Structures and Thoroughfares
Region:	Taranaki
Overview:	Advance Notice: New Plymouth District Council advises that an Open Request for Proposal will be released in the coming days for the Rogan Street Signalisation Project. NPDC is seeking suitably qualified and experienced contractors to deliver an intersection upgrade and associated civil works at the SH3 / Coronation Avenue intersection with Rogan Street, New Plymouth. This project presents an opportunity to partner with NPDC to enhance safety, improve traffic efficiency, and provide better access for all road users. The works have been programmed to take advantage of the 2026 summer school holiday period, minimising disruption to the travelling public and surrounding stakeholders while ensuring a strong focus on planning, coordination, and delivery excellence. Contractors interested in tendering are encouraged to ensure they are registered with NPDC on Tenderlink (https://www.tenderlink.com/npdc/). All tender documentation and associated information will be made available through Tenderlink once the RFP is released. We look forward to receiving proposals from experienced suppliers capable of delivering this important infrastructure improvement

Contract 27-003 Parks, Streets and Open Spaces Tree Maintenance

New Plymouth District Council — Thu, 13 Aug 2026 21:00:00 GMT

RFx ID:	34707671
Organisation:	New Plymouth District Council
Open date:	Friday, 14 August 2026 9:00 AM +12:00
Close date:	Wednesday, 16 September 2026 5:00 PM +12:00
Categories:	70110000 - Horticulture 72150000 - Specialized trade construction and maintenance services
Region:	Taranaki
Overview:	New Plymouth District Council (NPDC) is seeking a supplier with proven experience in tree maintenance services to provide tree maintenance across Parks, Streets, and Open Spaces. The purpose of this contract is to help keep Council trees safe, healthy, well-maintained, and sustainable for the future. Our overall objectives are to meet industry standards, support public safety, protect the amenity value of our green spaces, and meet community expectations. The services required include, but are not limited to:  Planned Operations and Maintenance  Reactive Maintenance  Routine Operations and Maintenance  Major Maintenance The supplier shall provide all labour, plant, equipment, supervision, and expertise necessary to deliver the services in a safe, efficient, and professional manner. This New Plymouth District Council tender will be accessible via Tenderlink, and is only being advertised via GETS. All further communications related to this tender will be conducted through TenderLink. To be able to participate in this tender and access the RFX documents, providers will need to ensure they are registered on TenderLink. The TenderLink portal is free to access and to upload submissions. We have published this advanced notice to alert potential respondents of the need to register in Tenderlink. Using the link below, please follow the instructions on the main screen of how to set up your organisation to access TenderLink (if you are not already registered). Please make sure your contact email address is accurate. https://www.tenderlink.com/npdc/ Please note, TenderLink is best accessed through Chrome. If you require any further assistance, please contact procurementadmin@npdc.govt.nz Ngā mihi, NPDC Procurement Team

25/26-217 Tūparikino Active Community Hub – Civils 2.0

New Plymouth District Council — Tue, 18 Aug 2026 01:00:00 GMT

RFx ID:	34731474
Organisation:	New Plymouth District Council
Open date:	Tuesday, 18 August 2026 1:00 PM +12:00
Close date:	Wednesday, 16 September 2026 12:00 PM +12:00
Categories:	30000000 - Structures and Building and Construction and Manufacturing Components and Supplies 72120000 - Nonresidential building construction services 72140000 - Heavy construction services
Region:	Taranaki
Overview:	This New Plymouth District Council tender will be accessible via Tenderlink, and is only being advertised via GETS. All further communications related to this tender will be conducted through TenderLink. To be able to participate in this tender and access the RFX documents, providers will need to ensure they are registered on TenderLink. The TenderLink portal is free to access and to upload submissions. New Plymouth District Council (NPDC) is seeking a suitably experienced and competent construction contractor to deliver the Tūparikino Active Community Hub Civil Package 2 in accordance with the scope of this tender. The contractor will be responsible for completing the required civil works within the Tūparikino programme during the 2026/27 summer period, demonstrating strong capability to coordinate effectively with concurrent and adjacent activities. The proposed methodology must ensure safe and continuous access at all times and minimise disruption to the ongoing vertical construction of the indoor arena (currently being delivered by Clelands), as well as the operations of TSB Stadium, NP Raceway, Pukekura Park, and surrounding properties. The contractor must be able to deliver within a constrained, high traffic, and operationally sensitive environment while maintaining programme, safety, and quality outcomes. NOTE: a. Any main contractor intending to submit a proposal must attend the mandatory Respondent Site Visit on 27th August 2026, 02:00 PM – 04:00 PM. Using the link below, please follow the instructions on the main screen of how to set up your organisation to access TenderLink (if you are not already registered). Please make sure your contact email address is accurate. https://www.tenderlink.com/npdc/ Please note, TenderLink is best accessed through Chrome. If you require any further assistance, please contact procurementadmin@npdc.govt.nz Ngā mihi, NPDC Procurement Team

27-008 Employee Assistance Programme (EAP) and Wellbeing Services

New Plymouth District Council — Mon, 17 Aug 2026 05:00:00 GMT

RFx ID:	34724436
Organisation:	New Plymouth District Council
Open date:	Monday, 17 August 2026 5:00 PM +12:00
Close date:	Wednesday, 16 September 2026 12:00 PM +12:00
Categories:	93131600 - Food and nutrition policy planning and programs 93131700 - Health programs
Region:	Taranaki
Overview:	This New Plymouth District Council tender will be accessible via Tenderlink, and is only being advertised via GETS. All further communications related to this tender will be conducted through TenderLink. To be able to participate in this tender and access the RFX documents, providers will need to ensure they are registered on TenderLink. The TenderLink portal is free to access and to upload submissions. New Plymouth District Council (NPDC) is seeking a suitably qualified and experienced provider to deliver a comprehensive Employee Assistance Programme (EAP) Service solution that supports the health, wellbeing, resilience and performance of Council employees and their immediate family members. The successful supplier will act as a strategic wellbeing partner, providing a proactive, accessible, confidential and responsive service. The supplier will be expected to support a diverse workforce through culturally responsive and inclusive services, maintain the highest standards of privacy and confidentiality, and work collaboratively with Council to identify emerging wellbeing trends, reduce psychosocial risks, improve workforce resilience and continuously enhance employee wellbeing outcomes throughout the term of the contract. - Confidential employee counselling services - Critical incident and trauma response services - Preventative wellbeing programmes and education - Digital wellbeing tools and resources - Comprehensive reporting and workforce wellbeing analytics - Multiple service delivery channels including face-to-face, telephone, video and online services - Support for employees and their immediate family members Using the link below, please follow the instructions on the main screen of how to set up your organisation to access TenderLink (if you are not already registered). Please make sure your contact email address is accurate. https://www.tenderlink.com/npdc/ If you require any further assistance, please contact procurementadmin@npdc.govt.nz NPDC Procurement Team